Trabajos project manager construction en New Rochelle, New YorkCrear alertas

Securitas Technology, part of Securitas, is a world-leading provider of integrated security solutions that protect, connect, and optimize businesses of all types and sizes. More than 13,000 colleagues in 40 countries are focused daily on our purpose to help make your world a safer place and our commitment to deliver an unparalleled client experience. With clients at the heart of all we do, our people, knowledge, and technology power our connected ecosystem of health, safety and security solutions and services. ORGANIZATIONAL RELATIONSHIPS Closely work with together with the BIM Manager and system’s design engineers to provide 3D design aid throughout the project’s life cycle. Reports to Enterprise Systems engineering manager. SCOPE OF RESPONSIBILITY The Engineer is responsible for working closely with the BIM Manager and Systems Engineer to create a 3D model of the integrated security systems design submittal for approval by the customer or representative and in accordance with project specifications, drawings, codes, and regulations, manage and create the design submittal (drawings, bill of material, calculations, as-builts, etc.) and maintain the submittal during changes to the contract. Work within Security Technology systems group on the design and integration of security systems, access control, intrusion detection systems, communication, CCTV, Intercom systems, computer, and networking. Develop detailed design schematic and review 2D and 3D drawings for electronic and electrical products. This position will require working closely with project managers, design engineers, engineering specialists, manufactures, customers, engineering firms and other external experts. This position will require working in the Elmsford-NY office or the Fair Lawn-NJ office. Travel if might needed is less than 10% of the time. There is no relocation package available for this position. Job Requirements: ESSENTIAL FUNCTIONS • Basic working knowledge of Electronic Security Systems and features., • Creating Detailed 3D Models utilizing Revit, AutoCAD, and Navisworks to develop detailed 3D models of architectural designs., • Work closely with Design Engineers, architects, and other team members., • Updating and Modifying Models. As plans and specifications change, update and modify existing models accordingly., • Generating 2D Drawings and Details. Extract 2D drawings and construction details from 3D models., • Clash Detection and Coordination. Run clash detection analyses to identify conflicts or discrepancies between different building elements., • Attend Regular Project clash detection meetings and be prepared with clash reports to facilitate coordination meetings among project stakeholders., • Adherence to BIM Standards. Ensure that all models comply with project-specific BIM standards and protocols., • Maintaining BIM Libraries. Create and update BIM families within the project’s library., • Contributing to BIM Standards Development and actively participate in enhancing BIM standards and best practices within the organization., • Ability to handle multiple projects, schedule work and communicate effectively to peers. ADDITIONAL RESPONSIBILITIES • Be prompt, reliable, and on time in all aspects of your engagement while maintaining a high level of attention to detail and accuracy., • Perform any additional duties as required or assigned. SPECIAL KNOWLEDGE, SKILLS, AND ABILITIES • Security engineering experience is preferred but not a must., • BS in EE Engineering or equivalent is required., • Computer skills to include Revit, AutoCAD, Navisworks and MS Office., • Knowledge of ISO 19650 standards, • AC and DC circuitry, voltage drop calculations and wire sizing., • Basic knowledge of network and system security principles, not only in theory., • Executing enterprise engineering techniques., • Proven experience managing workload and pressure situations. Securitas offers comprehensive benefits including: • Company training and industry leading certification program, • Opportunity for annual merit pay increases, • Medical, Dental, Vision, and Life Insurance, • Company Paid Short Term and Long-Term Disability, • 401K with 60% Match up to 6% of salary, • Paid vacation, holiday, and sick time, • Educational Assistance, • Exceptional growth opportunities, • Wide variety of employee discounts on travel, equipment, and more! We are a nationwide provider of security solutions and an equal opportunity employer committed to a diverse workforce. Our core values of Integrity, Vigilance and Helpfulness are proudly demonstrated daily by our employees to our customers and the communities we service.

\n • Under the supervision of the Project Manager, provides technical support to construction staff. Reviews plans and other technical documents, answers questions regarding the scope and/or timing of the project.\n, • Understands contract documents to help ensure compliance with drawings and contract specifications.\n, • Assists with procurement and vendor management.\n, • Supports the Project Manager in the supervision of the project as needed including the development of cost estimates or tentative schedules.\n\n \n \n \n\n • B.S. in Civil Engineering or related field\n, • Minimum of 0-2 years of experience in the construction industry required.\n, • Proficiency in Microsoft Office products.\n, • Experience with CAD software a plus.\n, • Motivated, independent, and self-sufficient.\n, • Highly organized and detail oriented with strong problem-solving skills.\n, • Ability to multitask and work in a fast-paced environment.\n, • Must be able to travel to jobsites and perform necessary manual tasks as required.\n\n \n \n \n \n PIa8765b320f96-25405-41719801

Controller | $150K–$175K + B \n Mount Vernon, NY | On-Site \n \n Atrium is seeking a Controller for a growing, technology-enabled mechanical and building-services company in Mount Vernon, NY. \n \n This isn't a "keep the books moving" Controller position. \n Reporting directly to the CFO, you'll take ownership of the accounting operation of a growing business while helping determine what the finance function should look like next. That includes financial reporting, close, project accounting and WIP, cash, controls, systems, process improvement and people leadership. \n \n The company is also actively investing time in AI and workflow automation, so we're looking for someone who is comfortable challenging old processes, learning new technology and thinking about how accounting can operate better as the business grows. \n \n Compensation: $150,000–$175,000 + B \n Schedule: Full-time, on-site \n Location: Mount Vernon, NY \n \n A background check may be run only after a conditional offer is made, where permitted by law. \n What You'll Do \n\n • Own the monthly and annual close and financial reporting process.\n, • Prepare and review P&L, balance sheet and cash flow statements and variance analysis.\n, • Oversee cash, reconciliations and support treasury forecasting.\n, • Provide oversight of payroll and related accounting.\n, • Lead billing, AR and collections.\n, • Own job costing, WIP, project financials and revenue recognition.\n, • Partner with operations on cost-to-complete, project margins and financial performance.\n, • Support tax filings, audits and regulatory requirements.\n, • Own and improve accounting processes across Sage Intacct, BuildOps and Coast.\n, • Manage and develop the accounting team.\n, • Work directly with the CFO on process improvement, automation and the continued evolution of the finance organization.\n\n \n What We're Looking For \n\n • Bachelor's degree in Accounting or Finance.\n, • Active CPA certification required.\n, • 7+ years of progressive accounting experience.\n, • Full-cycle close and financial statement preparation experience.\n, • Controller, Assistant Controller or Accounting Manager experience.\n, • Proven people-management experience.\n, • Strong US GAAP and internal-controls knowledge.\n, • Advanced Excel and mid-market ERP experience.\n, • Must be legally authorized to work in the United States.\n\n \n Great to Have \n\n • Construction, MEP or specialty-contractor accounting.\n, • Job costing, WIP, percentage-of-completion and retainage experience.\n, • AIA-style billing.\n, • Sage Intacct and/or BuildOps.\n, • Experience improving processes, implementing systems or introducing automation.\n\n \n Coming from another industry? Don't automatically count yourself out. Strong technical accountants who have worked in complex operating environments and can demonstrate curiosity, leadership and the ability to learn quickly are encouraged to apply. \n \n Why Join? \n Work directly with the CFO. You'll have real access to leadership and visibility into how the business operates. \n Build something. The accounting function is evolving, and you'll have an opportunity to influence the team, processes, systems and controls. \n Get hands-on with AI and automation. Leadership is actively exploring how emerging technology can improve finance workflows, giving you the chance to learn and build alongside them. \n Broaden your experience. You'll touch financial reporting, operations, WIP, project accounting, cash, systems, controls and people rather than one small area of accounting. \n Grow with the business. This is an environment where responsibility can expand significantly as the company and individual develop. \n \n Benefits \n If eligible under the ACA, medical, dental and vision benefits and time off in accordance with local paid sick time laws will be offered. Additional benefits may include paid holidays, a 401(k)-retirement plan, life insurance, disability coverage, and an employee assistance program, where applicable. Other compensation programs may include overtime, shift differentials, bonuses, commissions, or other incentive compensation, where applicable. \n \n Commitment to Diversity \n As a woman-owned firm, we value diversity. We are an equal opportunity and affirmative action employer and will consider all applications without regard to race, sex (including gender, pregnancy, sexual orientation and gender identity), age, color, religion or creed, national origin or ancestry, veteran status, disability (physical or mental), genetic information, citizenship or any other characteristic protected by law. \n We will ensure that individuals with disabilities are provided with reasonable accommodation to participate in the job application or interview process, to perform essential job functions, and to receive other benefits and privileges of employment. Candidates who apply for roles through the Atrium website will be added to our candidate pool and may be considered for additional roles of a similar title. Please contact us to request an accommodation. \n \n EOE/M/F/D/V/SO \n Applicant Communication Consent \n By applying to this job, you agree to receive calls, AI-generated calls, text messages, and/or emails from Atrium and its affiliates, and contracted partners. Frequency varies for text messages. Message and data rates may apply. Carriers are not liable for delayed or undelivered messages. You can reply STOP to opt out on any message you receive. \n For more details, please review our Terms of Use and Privacy Policy. \n \n Job Wrapping ID: #LI-AJ3

Job Description This job is posted on behalf of Galaxy Management Group, Inc. by Top Echelon. Position Title: Junior Structural Engineer Location: Pelham, New York Type: Full-Time FLSA Status: Non-exempt Reports To: Principal, Associate, Project Manager Position Overview Our Client, a growing structural engineering firm specializing in restoration and rehabilitation of existing buildings in the NYC metropolitan area, is seeking a motivated Junior Structural Engineer to join their team in Pelham, NY. This is an exciting opportunity for a recent graduate or early-career professional with a strong interest in restoration and structural engineering. The ideal candidate is curious, detail-oriented, eager to learn, and ready to contribute to our diverse and challenging projects. Essential Responsibilities • Assist in the investigation, analysis, and assessment of building structures and components., • Support the preparation of design documents, including drawings, reports, and specifications., • Conduct site visits and field inspections to document existing conditions and assist in construction observations., • Research building codes and materials relevant to projects under guidance from senior staff., • Collaborate with project managers and team members to ensure deadlines and quality standards are met., • Participate in internal meetings and client discussions as appropriate., • Continuously seek feedback and apply learning to improve technical and professional skills. Desired Skills and Qualities • Strong work ethic and commitment to continuous learning and professional growth., • Demonstrated interest in how things work—curiosity about buildings, systems, and structural behavior., • Ability to take direction, respond well to feedback, and work both independently and within a team., • Clear verbal and written communication skills., • Reliable time management skills and accountability for meeting deadlines., • Interest in pursuing PE licensure in the future., • Some relevant work experience (internships, co-ops, or office experience) preferred. Qualifications • Bachelor’s degree in Civil or Structural Engineering (required)., • 0-3 years of structural design experience is desired. We will consider recent grads with strong academic profiles, relevant internship experience, and a strong work ethic., • Engineer-In-Training (EIT), • Proficiency in AutoCAD and Microsoft Office Suite; familiarity with structural analysis software a plus., • Must have reliable transportation to job sites throughout the NYC metro area., • Comfortable with physical job site visits, including climbing ladders and scaffolding, and working at heights., • Knowledge of NYC/NYS Building Codes (preferred but not required). Why Join Us • Work closely with experienced engineers and gain hands-on project exposure from day one., • Be part of a tight-knit, passionate team in a collaborative, growth-oriented environment., • Opportunities to grow within a firm committed to mentoring and developing future engineering leaders. US Citizens or Valid US Green Card Holders Only No Relocation Assistance Provided

Construction Project Manager to join our office team.We are a well-established general contracting and construction management firm specializing in government, commercial, and public-sector construction projects.The ideal candidate must have at least 4 years of similar construction project managemen

Job Description Job Title: Field Operations Intern Employment Type: Intern Division: Field Operations Department: Field Operations Work Schedule: Full-time/40-hours - In Person Salary Range: $23 - $28/hour The Field Operations Intern supports Superintendents and Project Managers by assisting with safety program administration, quantity tracking, schedule analysis, and job site documentation. This role offers hands-on experience in field coordination, schedule management, and construction quality within a dynamic construction environment. Responsibilities / Essential Functions • Support the administration of the project safety program to ensure a safe and compliant work environment., • Provide technical assistance by interpreting contract drawings, submittals, and project documentation., • Assist the assistant superintendent, superintendent, and project manager with daily and weekly activities, including preparing daily reports, conducting safety walks, compiling quantity reports, and updating project schedules., • Develop a clear understanding of the overall project schedule, including critical path analysis., • Review and contribute to the short-term planning process to ensure project milestones are met., • Participate in the quality assurance program by attending meetings, performing site inspections, and verifying materials for compliance with project specifications., • Coordinate subcontractor activities to support adherence to project timelines and safety requirements., • Maintain project documentation such as daily logs, RFIs, and submittal tracking to support effective communication and record-keeping., • Monitor onsite material deliveries and inventory to facilitate uninterrupted project progress., • Participate in project team meetings, communicating updates, challenges, and potential solutions., • Observe and report site conditions that could impact schedule, cost, or safety., • Utilize construction management software and tools to accurately track and update project information. Key Skills • Strong written and verbal communication skills to clearly convey information and coordinate with team members, clients, and subcontractors., • Demonstrated interest in construction management and the construction industry., • Proactive problem-solving abilities with an analytical mindset and excellent attention to detail for tracking schedules, quantities, and quality inspections., • Effective time management and prioritization skills to handle multiple tasks and meet deadlines in a fast-paced environment., • Strong organizational skills to manage project documentation and communications., • Ability to work independently and collaboratively within team environments., • Adaptable and eager to learn, with a team-oriented approach to support multiple stakeholders and address site challenges proactively. Required Experience • Currently pursuing a Bachelor’s degree in Construction Management, Engineering, or related field; preference for Civil Engineering or construction-focused programs., • Basic knowledge of construction site safety standards, practices, and protocols., • Proficient in Microsoft Office Suite (Excel, Word, Outlook) with aptitude for learning construction management software., • Ability to read and interpret construction drawings, submittals, and technical documents., • Strong organizational skills for managing documentation and reporting., • Basic understanding of construction scheduling, including critical path method (CPM) concepts.

Company Overview \n Our client is an established and growing provider of commercial equipment solutions supporting complex construction and project-driven environments. The organization is expanding its presence in the Greater New York market and is seeking an experienced Project Manager to oversee commercial projects while supporting strong customer relationships and continued account growth. \n \n Position Overview \n We are seeking a Project Manager to manage commercial equipment projects from contract award through installation and completion. This role combines hands-on project management with a commercial focus, working directly with contractors, consultants, architects, customers, and internal teams to ensure projects are executed successfully and profitably. The ideal candidate understands construction environments, can interpret drawings, specifications, and contracts, and is comfortable managing both project execution and the customer relationship. \n \n Key Responsibilities \n\n • Manage projects from contract award and planning through procurement, installation, closeout, and final completion.\n, • Review drawings, specifications, contracts, submittals, schedules, and project requirements.\n, • Serve as a primary point of contact for general contractors, consultants, architects, customers, installers, vendors, and internal teams.\n, • Coordinate project schedules, equipment, materials, deliveries, installation crews, and site readiness.\n, • Monitor scope, costs, timelines, change orders, billing, and contract requirements to maintain project profitability.\n, • Identify scope additions, customer needs, and other opportunities to expand existing projects and accounts.\n, • Assist with pricing, proposals, change orders, and contract-related discussions.\n, • Build strong contractor and customer relationships that support repeat business and future project opportunities.\n, • Resolve field issues, scope discrepancies, scheduling conflicts, and other project challenges.\n, • Manage multiple active projects while maintaining accurate documentation, deadlines, and customer expectations.\n, • Support project closeout, punch-list completion, final documentation, and customer acceptance.\n\n \n Ideal Candidate \n\n • 3–5 years of project management, contract sales, or commercial experience within commercial construction, commercial equipment, or a similar project-driven industry.\n, • Experience managing projects from award through installation and completion.\n, • Ability to read and interpret construction drawings, specifications, contracts, and submittals.\n, • Experience working with general contractors, consultants, architects, design teams, and other construction stakeholders.\n, • Understanding of project financials, including costs, margins, pricing, change orders, and profitability.\n, • Commercial mindset with the ability to build customer relationships, identify opportunities, and support account growth.\n, • Strong communication, negotiation, organization, and problem-solving skills.\n, • Ability to manage multiple projects and competing priorities across both field and office environments.\n\n \n Compensation & Benefits \n\n • Competitive base salary based on experience.\n, • Performance-based incentive opportunity.\n, • Comprehensive benefits package.\n, • Mileage reimbursement for field travel.\n, • Career growth and advancement opportunities within a growing organization.\n\n

Simone Development Companies is a full-service, privately held commercial and residential real estate investment and development company with a distinguished resume and reputation established over five decades. As a full-service developer, we have the ability to rapidly move any project through site selection, acquisition, financing, construction, leasing, property management and maintenance. The core principles that define the Simone organization are the stability, creativity and professional expertise of our management team; an aggressive long-term business plan; a commitment to excellence and tenant service; our close relationships with strategic partners, tenants, lenders, municipalities, and real estate professionals; a consistent ability to add value; and most importantly, our unwavering pursuit of visionary development. Simone Development Companies is seeking a Construction Project Manager to join the in-house Development Construction department. Duties and Responsibilities: • Manage RFIs, submittals, schedules, budgets, scope changes, and other project documents., • Serve as the primary contact for clients, subcontractors, and stakeholders throughout the project., • Conduct regular meetings with key stakeholders to report on project progress., • Communicate project risks and propose mitigation strategies proactively., • Initiate and coordinate critical project meetings with internal staff, stakeholders, and external parties., • Maintain clear and effective communication with the project team., • Develop and manage project schedules., • Oversee construction progress and ensure updates are documented and reported., • Expertly interpret and manage construction drawings and documentation., • Outline and submit specifications as required., • Collaborate with clients and stakeholders to define project scope and delivery methods., • Apply knowledge of construction methods, materials, and industry standards to ensure quality and safety., • Negotiate and manage prime contracts, subcontracts, and vendor agreements while protecting financial interests and fostering positive client relationships., • Communicate effectively with internal and external parties, including customers and vendors., • Manage the design process to ensure timely delivery of quality and budget-conscious documents., • Create and validate financial forecasts for upcoming project activities., • Develop bid packages and solicit proposals as per internal policies., • Identify and address potential risks, developing strategies to mitigate their impact or capitalize on opportunities., • Develop feasible phasing plans and schedules that meet end-user needs Essential Skills and Abilities: • Cultivate relationships within client organizations to coordinate work and make decisions effectively., • Demonstrate exceptional organization, with the ability to oversee multiple projects concurrently., • Possess strong written and verbal communication skills, along with a proactive and independent work ethic., • Proficiency in Microsoft Project or Primavera P6, Microsoft Office Suite, and Bluebeam., • Ability to comprehend ARCH & MEP drawings and reports, with a focus on identifying potential improvements for project implementation. Required Education & Experience: • Bachelor’s degree from an accredited institution in Architecture, Engineering, or Construction Management is preferred., • Experience in lieu of a degree is acceptable., • 7-10 years of relevant construction industry experience., • Experience in interiors, mechanical, civil, or utility services. This job description is not designed to cover or contain a comprehensive listing of activities, duties or responsibilities that are required of the employee. Duties, responsibilities and activities may change, or new ones may be assigned at any time with or without notice. Additional Comments on Working Environment • Must be able to lift, carry, push, pull a maximum of 50 lbs., • Ability to walk the job site frequently, including climbing stairs and ladders, • Exposure to varying weather conditions typical of active construction sites, • Ability to perform routine office tasks that includes operating a computer for long periods of time, sitting, filing and communicating on the phone Equal Employment Opportunity Requirements It is the policy of Simone Development (SIMDEV) to provide equal employment opportunities to all qualified individuals without regard to race, color, creed, religion, national origin, ancestry, age, gender, pregnancy, sexual orientation, gender identity or expression (including transgender status), age, marital status, familial status, citizenship status, disability or genetic information or handicap or status as a Vietnam-era or special disabled veteran in accordance with all applicable federal, state and local laws.

Simone Development is a full-service, privately held commercial and residential real estate investment and development company with a distinguished resume and reputation established over five decades. As a full service developer, we have the ability to rapidly move any project from site selection, acquisition, financing, construction, leasing, property management and maintenance. The core principles that define the Simone organization are the stability, creativity and professional expertise of our management team; an aggressive long-term business plan; a commitment to excellence and tenant service; our close relationships with strategic partners, tenants, lenders, municipalities, and real estate professionals; a consistent ability to add value; and most importantly, our unwavering pursuit of visionary development. Position Summary The Property Manager creates tenant satisfaction and retention by facilitating the initial installation of the tenant, fostering two-way communication channels, implementing clearly understood life safety programs, and responding to tenant requests in a timely and effective manner. The Property Manager maximizes portfolio value by maintaining the properties, budgeting and managing operational expenses, and by identifying and implementing capital improvements that will increase the efficiency and value of the properties. In so doing, the Property Manager operates in alignment with the vision, mission and strategy of Simone Development team in a manner consistent with our core values. Job Responsibilities • Assure that the property is maintained and operated at a level that 1) causes tenants to be highly satisfied and inclined to want to continue as tenants beyond lease expiration, 2) causes potential tenants to be positively impressed, and 3) adds to the good reputation of the property and its owners., • Respond to the demands of tenants in a timely and responsive manner, and handle “non-legitimate” demands in an effective manner., • Maintain professional, working relationship with all tenants at assigned properties., • Determine whether the responsibility for repair/maintenance is the responsibility of the Landlord or the Tenant, and communicate to the Tenant when repair/maintenance is not the Landlord’s responsibility. When work is performed, work with the PM team to follow up with tenant to be sure the complaint is resolved., • Rapidly respond to emergency situations and coordinate solutions with the team., • Oversee Construction department in coordinating tenant build-outs, reconfigurations and expansions, etc., at assigned properties., • Review vendor contracts with SVP Property Management, and oversee and maximize the service delivery, output, and effectiveness of all vendors and contractors., • Bid, negotiate and implement service contracts with all 3rd party vendors in accordance with company policy., • Ensure properties are compliant with all building and fire codes., • Assist in showing space to brokers and potential tenants, initiate lease discussions when appropriate, and assist with determining floor layouts and work letters, as needed., • Work with the VP Leasing, as needed, on lease renewals., • Maintain a full knowledge of and be responsible for all activities at assigned properties., • Approve bill-backs, CAM, etc., and make sure they are collected in a timely manner., • Review and approve Purchase Orders and invoices related to the properties., • Assist with rent collection and other tenant receivables., • Prepare information needed for landlord/tenant court and appear in court as owner’s representative., • Prepare the annual operating and capital budgets and monthly variance reporting for assigned properties., • Monitor year-to-date actual vs. budget to assure that the property is running within budget., • Document any significant variances in writing and be prepared to discuss them at the budget review., • Review CAM reconciliations and resolve discrepancies with Property Accountants before invoices are sent to tenants., • Explain CAM charges and RE taxes when challenged by tenants, with assistance from Property Accountants when needed., • Communicate orally, and coordinate registered letter process, with any tenant who is violating lease terms (e.g., parking in wrong spaces, leaving garbage in wrong place, etc.) – or who is otherwise causing use-of-space or care-of-space problems., • Assure all utility meters are being read and billed as actual (not estimated), and work with the Property Management team at least five days prior to Tenant vacating to make sure utility accounts are switched over to owner’s name to avoid lapse in services (gas, electric, water, etc.). Assure that a master list of meter numbers is maintained correctly., • Resolve issues related to any meters/addresses that are not being billed correctly., • Work with Assistant Property Management to report all damage, injuries or potential claims to the legal department immediately with a detailed incident report containing all pertinent facts, names, dates, times, locations, etc., • Assure that “move out” and “move in” processes are completed in a timely manner and that properties are in optimum condition for leasing., • Value engineering of alternative methods of repair and/or replacement of equipment., • Visit properties frequently and report work order requests through the work order management system., • Work with the Property Compliance Manager to assure that the tenant always maintains proper insurance., • Work with Property Compliance Manager and liaison with Building Departments to coordinate activities needed to obtain Certificates of Occupancy (TCOs & Cos), clear violations, obtain permits, comply with code requirements, etc., • This job description is not designed to cover or contain a comprehensive listing of activities, duties or responsibilities that are required in this role., • Duties, responsibilities and activities may change or new ones may be assigned at any time with or without notice., • Other tasks/assignments/research as needed. REQUIREMENTS: • Bachelors degree preferred, • 5+ years of Building Operations/Management experience in a New York City Class A Office Buildings, • Working knowledge and experience with Payscan, Yardi, Construction Manager and Facility Manager preferred, • Excellent MS Excel skills, • Comprehensive knowledge of NYC local building codes, • Must have understanding of accounting procedures and financial reports It is the policy of Simone Development (SIMDEV) to provide equal employment opportunities to all qualified individuals without regard to race, color, creed, religion, national origin, ancestry, age, gender, pregnancy, sexual orientation, gender identity or expression (including transgender status), age, marital status, familial status, citizenship status, disability or genetic information or handicap or status as a Vietnam-era or special disabled veteran in accordance with all applicable federal, state and local laws. Recruiters need not reach out. The organization is sourcing candidates directly at this time.

The Assistant Property Manager provides operational and administrative support to the Property Management team in the day-to-day management of an assigned portfolio of commercial properties. This role serves as a key point of contact for tenants, vendors, and onsite personnel while helping ensure properties are maintained to the highest standards, work orders are completed efficiently, and property operations run smoothly. Key Responsibilities: • Maintain positive tenant relationships by promptly addressing service requests and coordinating repairs, maintenance, and construction., • Assist Property Managers with property inspections, compliance reporting, and corrective actions., • Support daily property operations, vendor coordination, scheduling, and project oversight., • Coordinate with building managers, maintenance teams, contractors, engineers, and vendors to ensure timely completion of work., • Manage work orders, service contracts, tenant communications, and property records. Assist with tenant move-ins, move-outs, and occupancy changes., • Conduct property walkthroughs to identify maintenance, safety, and operational needs., • Assist with invoice processing, accounts payable, budget tracking, and preventative maintenance programs., • Support annual mall operating guideline distribution and collection., • Provide general administrative support to the Property Management team and assist with special projects as needed. Qualifications • An associate or bachelor’s degree in business administration, Real Estate, Property Management, or a related field is preferred. Candidates with at least three 3 year, • of relevant experience may also be considered in place of a degree., • Working knowledge of commercial property management, lease administration, building operations, and applicable regulations., • Experience coordinating maintenance, contractors, vendors, and property-related projects. Knowledge of operating and capital budgets., • Proficiency in Microsoft Office Suite, including Outlook, Word, and Excel; property management software experience is a plus., • Strong organizational, multitasking, time management, and attention-to-detail skills., • Excellent written and verbal communication skills with a customer-focused approach., • Ability to work independently and collaborate effectively with tenants, vendors, contractors, onsite teams, and internal departments., • Ability to manage multiple priorities, meet deadlines, and work effectively in a fast-paced environment

A Water and Wastewater Practice Leader at H2M architects + engineers grows, develops, supports and enhances our scope of Water and Wastewater services work in a Doer-Seller role. In this role, you will provide project management and technical expertise for water/wastewater projects, and client relationship management including business development and coordination of key Water/Wastewater and Municipal services. A Practice Leader is responsible for strategically growing business development efforts along with supporting technical aspects of water/wastewater and municipal projects/operations. With over 90 years of experience in water and wastewater engineering, H2Ms water and wastewater team designs and implements drinking water treatment systems, distribution networks, wastewater treatment facilities, pump stations, and collection systems. We support water districts, municipalities, and regional authorities in meeting regulatory requirements and improving system reliability and environmental performance. Our work protects public health, enhances sustainability, and ensures essential services remain resilient for the communities that depend on them. Key Responsibilities • Assist in the development and implementation of strategy for further development in the Water/Wastewater Groups., • Work with the Market Leader and/or Discipline Director to implement a plan for growth of the market in existing and new service areas, as well as new areas as highlighted in the annual business plan for the Market., • Financial proficiency in establishing project-related fees and aggressive revenue projections and profit margins is required., • Ability to manage a team of professionals., • Working closely with all disciplines to implement and manage projects that fall under the Water/Wastewater group and establish staffing needs, achievable project schedules and meet established deliverable timelines, and produce an excellent work product, all while ensuring client satisfaction with overall services., • Assist where needed in the preparation of a detailed discipline plan and determine where potential funding opportunities may exist., • Assist where needed with the marketing team to produce business plan materials pertinent to the market., • Ensure the H2M standard procedures and processes are being utilized and maintained., • Attend trade shows, client presentations and meetings, develop articles, blogs, social media, and press releases to help showcase H2M and the Water/Wastewater Group with a goal to promote H2M’s presence in the market and region., • Prepare/coordinate proposals in conjunction with the marketing and technical staff. Assist with “Go/No Go” decisions for responding to RFP’s. Marshall the necessary resources on proposal opportunities which may involve developing a proposal strategy, writing portions of the proposal, and coordinating efforts of other technical writers to develop a winning proposal., • Coordinate and communicate with staff to ensure project deadlines and client requirements are being met and provide technical leadership and oversight on the management of project. Work with other managers and water/wastewater professionals to develop scope of work, budgets, and plans for water/wastewater related work., • Assist with the development efforts of the regional office’s overall growth and development of the staff in the discipline., • Develop a sense of team with the staff you work alongside and your manager. This will typically involve spending a significant amount of time with the discipline staff, getting to know them and their capabilities. May enlist key people within the firm to assist and drive important discipline-related initiatives., • Responsible for making sure we provide excellent customer service both internally and externally. Will respond to requests of others as needed and set up a communication protocol for existing and future clients to ensure their needs are met. This includes communication with department managers within the discipline. Education & Qualifications • Bachelor's degree in mechanical, environmental, or chemical engineering is required., • 15+ years’ experience in the business of consulting Water/Wastewater engineering for municipal, private, and public agency clients, • P.E. required with the ability to gain reciprocity in multiple states in which H2M operates., • Relevant knowledge of project management, design, construction, operations, and administration of Water/Wastewater infrastructure is required., • A strong technical background in water/wastewater engineering is required., • Successful track record of performance for obtaining new clients and in creating new projects for existing clients. Additional Requirements • This role requires some travel. Business-related travel may involve visits to project sites, professional events, client locations, and other H2M offices and may require the use of a personal vehicle., • This is an exempt, salaried role that may occasionally require flexibility outside standard business hours, including evenings, weekends, and select holidays, to support project schedules, client needs, and business priorities. Compensation & Benefits • The salary range is between $140,000 to $195,000 annually., • Comprehensive medical, dental, and vision healthcare coverage., • 401(k) with up to 6% employer match and Profit-Sharing Bonus Program., • Student loan repayment and tuition assistance to support professional accreditation and continuing education., • Paid Time Off (PTO) and Holidays, and flextime to Balance Work and Life., • Access to professional development programs including mentoring, training, and early-career support., • Active Employee Resource Groups including: Diversity & Inclusion, Sustainability, Women’s Initiative, and Young Professionals., • Check out our _. pushing boundaries. redefining design. Apply today and start your journey with H2M. The employment offer may deviate from the published range based on a variety of factors, including but not limited to, experience, specialty, knowledge, education, geography and/or related certifications – not related to any applicant’s characteristics protected by local, state or federal law. Note: The salary or hourly rate indicated does not include other forms of compensation or benefits.

Drafting Manager - NY Job ID: JOS2223 Starting base salary: $150,000- $200,000 Summary Seeking an experienced Architectural Woodwork Drafting Manager to lead the technical design, millwork detailing, and production of shop drawings for custom cabinetry, architectural woodwork, wall paneling, and fine furniture. This role serves as the bridge between design intent, engineering requirements, and shop-floor fabrication, ensuring projects are delivered accurately, on budget, and in accordance with quality and field conditions. Responsibilities Millwork Detailing: Develop and oversee the creation of precise shop drawings and detailed architectural woodwork documentation. Design Coordination: Translate architectural and interior design concepts into buildable, structurally sound millwork solutions. Field Verification: Coordinate and verify site measurements and field dimensions prior to fabrication and production. Material Selection: Specify appropriate materials, hardware, and finishes in accordance with project requirements and performance standards. Production Oversight: Provide technical guidance to drafting personnel and communicate fabrication requirements directly with manufacturing teams. Quality Control: Review submittals, mock-ups, shop drawings, and completed assemblies to ensure compliance with project specifications and quality standards. Requirements Experience: Minimum of 6 years of experience in architectural woodwork, millwork drafting, custom cabinetry, or high-end residential/commercial construction. Software Skills: Proficiency in AutoCAD is required. Experience with Revit and/or specialized millwork or cabinetry design software is preferred. Technical Knowledge: Strong understanding of woodworking methods, joinery systems, fabrication processes, woodworking machinery, and finishing techniques. Communication: Ability to effectively collaborate with project managers, contractors, field personnel, designers, architects, and manufacturing teams For consideration & more info send your resume (in Word.doc) & contact exclusively: Brian Jackson, VP WoodJobs.com Global Woodwork & Fixture Industry Recruiters

Job Title: Project Manager – HVAC Location: Queens and/or Westchester Salary: up to $180K Company Overview: We are a leading HVAC company specializing in high-rise and new construction projects throughout the boroughs. We pride ourselves on delivering exceptional mechanical solutions with a focus on quality, safety, and efficiency. Position Overview: We are seeking an experienced and highly skilled Project Manager to oversee HVAC projects in new construction high-rise buildings across NYC boroughs. The ideal candidate will have strong expertise in piping systems, a track record of managing complex projects, and the ability to coordinate effectively with clients, subcontractors, and internal teams. Key Responsibilities: • Manage all phases of HVAC projects from pre-construction through completion., • Oversee project schedules, budgets, and resources to ensure timely and cost-effective delivery., • Coordinate with engineers, architects, subcontractors, and vendors to ensure project requirements are met., • Review and interpret blueprints, specifications, and piping designs., • Monitor quality control and ensure compliance with safety regulations., • Provide regular project updates and reports to senior management., • Troubleshoot and resolve project-related issues promptly. Qualifications: • Proven experience as a Project Manager in HVAC, with a focus on new construction high-rise projects., • Strong knowledge of piping systems and mechanical installations., • Excellent organizational, communication, and leadership skills., • Ability to manage multiple projects simultaneously., • Familiarity with construction codes, regulations, and industry standards in NY., • Bachelor's degree in Mechanical Engineering, Construction Management, or related field preferred, but equivalent experience will be considered. What We Offer: • Competitive salary and benefits package., • Opportunities to work on high-profile projects across Long Island and NYC., • Collaborative and supportive work environment., • Professional growth and advancement opportunities.

The ideal candidate would have hands-on experience building and updating CPM schedules in Primavera P6 for NYC public work—ideally projects involving agencies such as SCA, NYCHA, DDC, DEP, DASNY, MTA, Port Authority, DCAS, or similar government owners coming from a consultant agency GC or Specialty contractor As an Scheduling Engineer WDF, Inc., you will have the opportunity to: • Develop project schedules for all phases of the project, from pre-construction through close-out., • Collect, verify, and enter schedule progress information, including actual start and finish dates, remaining durations, and percent complete., • updating project schedules and preparing progress and performance reports., • Support the Scheduling Manager and project teams in maintaining accurate, timely, and logically sequenced schedules., • Coordinate with the Construction, Project Management, Design, Procurement, and Cost Control teams to gather schedule information., • Help review subcontractor schedules, short-term look-ahead schedules, and supporting schedule narratives., • Assist with creating schedule fragments for Time Impact Analyses, recovery plans, and scenario studies., • Support the preparation of preliminary schedule analyses for completed, ongoing, and future work., • Participate in pull-planning sessions and schedule review meetings with field teams, consultants, and subcontractors., • Maintain scheduling data from change order, procurement, submittal, RFI, billing/requisition, commissioning, and close-out logs., • Assist with identifying schedule variances, potential delays, critical-path activities, and upcoming milestones for review by the Scheduling Manager., • Prepare meeting materials, schedule reports, charts, and presentations as directed., • Support earned value analysis, cost and resource loading, schedule modeling, claims documentation, and other scheduling assignments., • Maintain organized schedule files, update logs, and supporting documentation in accordance with project procedures., • Perform quality checks on schedule data and promptly communicate incomplete or inconsistent information to the Scheduling Manager. REQUIREMENTS: • Bachelor's degree in Engineering, Architecture, Construction Management, or a related field from an accredited institution., • Working knowledge of construction sequencing, scheduling concepts, and project controls fundamentals., • Experience with Primavera P6 preferred; proficiency in Microsoft Excel required., • Ability to review project information, organize data, and prepare accurate reports under the direction of the Scheduling Manager., • Strong verbal and written communication skills., • Ability to manage multiple assignments, meet deadlines, and work effectively in a team environment., • Willingness to learn schedule development, progress measurement, critical-path analysis, earned value management, and time-impact analysis.

The ideal candidate is basically a senior contractor-side builder who has already been functioning above the PM level, even if their current title is Senior PM or Project Executive from a General Contractor, Self performing contractor , or specialty contractor and have experience managing NYC agency/public works projects for organizations such as SCA, NYCHA, DDC, DASNY, DEP, DCAS, DSNY, DOE, or similar public agencies. Job Summary: We are seeking an experienced and results-driven Field Operations Manager to oversee and coordinate construction activities across multiple projects. The ideal candidate will be responsible for managing day-to-day operations, improving performance, driving efficiency, and ensuring the timely and cost-effective delivery of high-quality construction projects. Description: Project Planning & Execution • Lead the planning, execution, and completion of construction projects within time and budget., • Coordinate with project managers, engineers, and site supervisors to align schedules and deliverables., • Oversee resource allocation, including labor, materials, and equipment. Operational Oversight • Monitor and evaluate overall company operations to improve productivity and reduce costs., • Develop and implement operational procedures and best practices., • Track project KPIs and report performance to senior management. Team Leadership & Management • Recruit, train, and manage operations staff, site teams, and subcontractors., • Promote a culture of accountability, safety, and continuous improvement., • Ensure compliance with labor laws, health and safety regulations, and company policies. Quality Assurance & Compliance • Implement quality control standards and supervise compliance at all project sites., • Conduct site inspections and risk assessments., • Ensure adherence to all regulatory and legal requirements in construction operations. Client & Stakeholder Communication • Maintain strong relationships with clients, suppliers, and consultants., • Provide regular updates to stakeholders on progress, risks, and key decisions., • Support the business development team in preparing bids and project proposals. Budget & Cost Control • Monitor project budgets and financial forecasts., • Approve procurement of construction materials and services., • Identify cost-saving opportunities and minimize operational inefficiencies. Requirements: • Bachelor’s degree in Civil Engineering, Construction Management, or related field (Master’s preferred)., • 15+ years of construction experience, preferably with a General Contractor or self-performing contractor in the NYC market, with at least 5 years in a senior project, field or operational leadership capacity., • Strong experience managing and overseeing multiple concurrent construction projects, Project Managers, Superintendents and field teams., • Experience with NYC public-agency construction strongly preferred, including SCA, NYCHA, DDC, DASNY, DEP, DSNY, DOE, CUNY, SUNY or similar agencies., • Proven ability to manage projects from preconstruction/estimating through field execution and final closeout., • Strong understanding of project financials, cost-to-complete, forecasting, change orders, billing, scheduling, delay documentation and contractual requirements., • Experience with fast-paced, short-duration projects, occupied facilities and projects with aggressive or hard turnover dates., • Strong knowledge of construction means and methods, building codes, safety requirements, subcontractor management and field operations., • Demonstrated ability to identify troubled projects, resolve field and schedule issues, manage resources and protect project profitability., • Working knowledge of HVAC, plumbing, fire protection and general MEP coordination is preferred; deep mechanical expertise is not required., • Strong knowledge of construction processes, building codes, safety regulations, and project management methodologies., • Proficient in project management software (e.g., MS Project, Primavera, AutoCAD, Procore)., • Excellent leadership, communication, and problem-solving skills., • Excellent written and verbal skills

Job Description Site Superintendent – Lead Commercial MEP & Heating Retrofit Projects for Dual Fuel Job Overview Company: Dual Fuel Company LLC Salary/Pay Rate: $100,000–$135,000+ per year (Plus Project Completion and Performance Bonuses) Location: Mount Vernon, NY (Field-Based Throughout NYC's Five Boroughs, Primarily Manhattan and the Bronx) Job/Employment Type: Full Time Schedule: Monday–Friday (Flexibility Required for Project and Job-Site Schedules) Project Scope: Turnkey Commercial Boiler Plant Installations & MEP Plumbing Retrofits ($0.5M–$25M Scope) Mandatory Licenses & Certifications: Valid Driver's License, OSHA 30 Certification, NYC SST Card (40-Hour) The Opportunity Dual Fuel is seeking an experienced, hands-on Site Superintendent to serve as the primary on-site authority for active mechanical, plumbing, and energy installation projects throughout New York City's five boroughs. In this high-impact field role, you will take ownership of site quality, safety, subcontractor management, and daily construction activities from mobilization through closeout. You'll lead crews, coordinate complex commercial boiler and MEP installations, anticipate challenges, and keep projects moving safely and efficiently. We're looking for a confident field leader who can independently manage job-site operations, make sound decisions, and maintain close communication with project management. The ideal candidate brings strong commercial mechanical expertise and the ability to manage field execution with the organization, accountability, and ownership of a project manager. How You Will Make an Impact • Submit detailed Construction Daily Reports and Safety Reports every day via company management platforms to document crew activity, site hazards, and project progress., • Direct internal foremen, trade crews, and subcontractors in executing complex commercial boiler, heating, and MEP installations according to engineering specifications., • Prepare and manage two-week construction look-ahead schedules while tracking man-days against project budgets to identify and address schedule deviations early., • Independently oversee daily job-site operations, resolve field challenges, and maintain accountability for project safety, quality, productivity, and progress., • Enforce rigorous quality control standards, job hazard analyses, hot work permits, and site safety compliance throughout project execution., • Coordinate field sequencing between internal trades, equipment deliveries, and building operators to maintain critical path schedules., • Facilitate on-site meetings with engineers, clients, and municipal inspectors while communicating scope changes and field conditions to project managers., • Conduct operational handoffs and client training on newly installed mechanical equipment upon project completion. Required Qualifications & Experience • Five or more years of commercial MEP construction leadership experience preferred, with strong knowledge of commercial boilers and heating systems. Candidates with slightly less experience may be considered based on demonstrated field leadership, technical expertise, and ability to manage projects independently., • Advanced working knowledge of steam heating systems, hydronic heating and cooling, pumps, fuel oil systems, and NYC mechanical codes., • Proven ability to independently supervise construction activities, coordinate crews and subcontractors, resolve job-site challenges, and maintain project schedules., • Ability to read and interpret construction schematics, architectural drawings, RFIs, and technical submittals., • Proficiency in using project management and field communication software for daily reporting and schedule tracking., • Reliable transportation and the ability to travel to project sites throughout New York City's five boroughs—Manhattan, the Bronx, Brooklyn, Queens, and Staten Island—with most projects concentrated in Manhattan and the Bronx., • Ability to work on-site throughout active construction operations, accommodate early morning starts when required, and remain available to supervise crews through the completion of scheduled daily activities., • Willingness to attend occasional project meetings at the Mount Vernon office., • Possession of a valid Driver's License, OSHA 30 Certification, and an active NYC SST Card (40-Hour). Preferred Qualifications & Experience • Bachelor's degree in Mechanical Engineering, Construction Management, or a related technical discipline., • Hands-on experience with combined heat and power (CHP) cogeneration systems, chillers, or general HVAC retrofits., • Direct experience working on prevailing-wage, NYCHA, and affordable housing portfolio projects., • Familiarity with field service and construction management platforms such as BuildOps, ServiceTitan, Procore, or MS Project. Compensation & Benefits • Salary options ranging from $100,000 to $135,000+ per year, with project completion and performance-based bonuses., • 401(k) retirement savings program with employer matching contributions., • Comprehensive medical, dental, and vision insurance coverage., • Health Savings Account (HSA) options and company-paid life and disability insurance., • Paid time off for holidays, vacation, and sick leave, alongside paid parental leave., • Specialized safety equipment, PPE, and technical field tools provided., • Employer-funded safety training, trade certifications, and career development programs., • Team-building company events and employee referral bonus program. About Us Dual Fuel is a $50M+ mechanical contractor, ESCO, and Licensed Master Plumber delivering commercial heating, boiler plant upgrades, and energy efficiency retrofits across NYC and Westchester. Operating with a data-driven approach and proprietary automation technologies, we empower our field leaders to own complex projects with full transparency and direct support. Learn more at https://www.dualfuelcorp.com/. Dual Fuel is an Equal Opportunity Employer and does not discriminate on the basis of race, color, religion, sex (including pregnancy, gender expression, and sexual orientation), parental status, national origin, age, disability, genetic information (including family medical history), political affiliation, military service, or any other status protected by law or regulations. It is our intention that all qualified applicants be given equal opportunity and that selection decisions be based on job-related factors.

Job Description We are hiring! ACS System Associates, Inc. established in 1983 is one of ENR top rated MBE privately held HVAC Commercial Companies. ACS is renowned for projects such as World Trade Center, Brooklyn Navy Yard, Stony Brook Hospitals, and a wide variety of both private and public work projects in the Greater New York area including Westchester, New York City, and Long Island. The diverse portfolio includes retail, office, industrial, hotel, schools, and hospital projects. We have an internal division complete with engineers, architects, draftsmen, project managers, and supervisors. These specialists work with clients such as Tishman, Turner, and Lend Lease to make sure each project is done effectively, on time, and within budget. We offer a lucrative benefits package to our employees that include Medical, Dental, Vision, 401K, PTO, Life Insurance, Education reimbursement to name a few. Headquartered in Long Island, NY with additional offices in Westchester County. We are seeking experienced Site Supervisors with HVAC knowledge as we expand. Key Duties & Responsibilities: • Managing and maintaining the project schedule from start to finish., • Working with the Project Manager, General Contractor, other trades, and suppliers to resolve issues/questions in a timely and cost-effective manner., • Adhering to plans specifications., • Reviewing all work for quality and accuracy., • Coordinating workers to meet the project schedule., • Reviewing and managing supplier deliveries., • Ensuring the cleanliness of site, • Ensuring that all site activities comply with safety regulations and procedures., • The coordination of subcontractors (as needed), • Engaging in hands-on work to keep the project on schedule., • Reporting and tracking on-site changes and progress, • Embracing teamwork with all trades to complete the project., • Must have current SST 62, • Must use own car Requirements: • 5 years of superintendent/field manager experience in the HVAC or General Contracting, • Proven track record of successfully completing projects on time and on budget., • Valid OSHA 30-hour and NYC DOB SST62 certification, • Proficiency with construction management software, • Must either live in Nassau, Western Suffolk, Within 5 Boroughs of NYC or Westchester Primary Location: United States-New York-Hicksville Other Locations: United States-New York-Westbury Other Locations: United States-New York-Mount Vernon Applicants must be authorized to work in the U.S. All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, national origin, disability, protected veteran status, or any other characteristic protected by law. • Job Type: Full-time\nCompany Description, • With a $ 250 Million Bonding Line, ACS is a Major Player in Government and Private Construction Contracts., • Job Stability to our Team Members is ensured by Dozens of Ongoing Contracts at all times in NYC 5 Boros ,L.I, Ct and the vicinity., • We are looking forward to expand our Team to take on challenging assignments as we embark on Major Expansion., • Our Associates are our Most Valued and Greatest Corporate Asset .We seek to maximize this Asset by assisting all our Associates ,in every which way, in realizing their Highest Professional Potential. Additionally ACS regularly works on HUD Section 3 Projects with hiring priorities for low-income persons., • With a $ 250 Million Bonding Line, ACS is a Major Player in Government and Private Construction Contracts.\n\n Job Stability to our Team Members is ensured by Dozens of Ongoing Contracts at all times in NYC 5 Boros ,L.I, Ct and the vicinity.\n\n We are looking forward to expand our Team to take on challenging assignments as we embark on Major Expansion. \n\n* Our Associates are our Most Valued and Greatest Corporate Asset .We seek to maximize this Asset by assisting all our Associates ,in every which way, in realizing their Highest Professional Potential. Additionally ACS regularly works on HUD Section 3 Projects with hiring priorities for low-income persons.

Under the supervision of the Project Manager, provides technical support to construction staff.Reviews plans and other technical documents, answers questions regarding the scope and/or timing of the project.Understands contract documents to .Assists with procurement�

Job Description Namdar Group is a premier real estate development firm based in Great Neck, NY, specializing in ground-up multifamily and high-rise residential development. We are dedicated to shaping city skylines and building vibrant residential communities through innovative architectural design, meticulous technical planning, and exceptional project delivery. As an Architectural Project Manager / Design Manager, you will lead large-scale multifamily and high-rise residential projects from conceptual design through design development, construction documents, permitting, and construction administration. You will manage project schedules, design deliverables, and consultant coordination while ensuring projects remain within scope and meet our quality standards. You will serve as the central point of contact between ownership, architects, structural engineers, MEP consultants, civil engineers, contractors, and municipal authorities, coordinating all aspects of the architectural design process. Responsibilities include reviewing architectural drawings, construction documents, Revit and AutoCAD files, resolving design conflicts, coordinating MEP and structural systems, and supporting DOB/building department approvals and permitting for complex ground-up developments.

Job Description Job Title: Construction Project Manager – Ground-Up & Interior Renovation Projects Location: Westchester County & NYC (5 Boroughs) Compensation: $125,000 – $170,000+ based on experience Schedule: Full-Time | In-Office / On-Site | No Remote or Hybrid About the Opportunity Our client, a highly respected and growing construction management/general contracting firm, is seeking experienced Construction Project Managers to oversee a diverse portfolio of commercial construction projects throughout Westchester County and the NYC 5 Boroughs. This role is ideal for professionals with strong experience managing ground-up construction and/or interior renovation projects across sectors such as commercial office, retail, mixed-use, hospitality, and corporate interiors. The company offers long-term growth, a collaborative team environment, and a steady pipeline of active projects throughout the region. Key Responsibilities • Manage projects from pre-construction through closeout, • Oversee all aspects of scheduling, budgeting, subcontractor coordination, procurement, and project execution, • Lead day-to-day communication with clients, architects, engineers, consultants, and field teams, • Review and manage RFIs, submittals, change orders, contracts, and project documentation, • Coordinate with Superintendents to ensure project schedules, safety standards, and quality expectations are maintained, • Track project costs and maintain budget control throughout all phases, • Conduct regular project meetings and provide detailed progress updates to stakeholders, • Ensure all work complies with local building codes, safety regulations, and company standards, • Identify and proactively resolve project challenges to minimize delays and cost impacts, • Maintain strong relationships with clients, vendors, and subcontractors throughout the project lifecycle Qualifications • Minimum 5–10+ years of Project Management experience within the construction industry, • Proven experience managing:, • Ground-up construction projects, • Interior renovation / fit-out projects, • Commercial, retail, mixed-use, hospitality, or corporate interiors projects, • Strong knowledge of NYC and Westchester construction processes and regulations, • Procore proficiency is required, • Experience with project scheduling, budgeting, buyouts, and subcontractor management, • Ability to manage multiple projects simultaneously in a fast-paced environment, • Excellent leadership, communication, and organizational skills, • Strong understanding of construction drawings, specifications, and project sequencing, • Bachelor’s degree in Construction Management, Engineering, Architecture, or related field preferred Additional Information • Stable pipeline of active projects throughout NYC and Westchester, • Highly visible role with opportunity for long-term advancement, • Competitive compensation package based on experience, • Full-time in-office and field presence required If you are an experienced Construction Project Manager seeking a long-term opportunity with a well-established and growing construction firm, we encourage you to apply.

Job Description Enter Job Description... Project Overview • The Project Engineer I supports the Customer Project Delivery department in achieving the Business Unit's goals to improve energy efficiency and stimulate new energy technologies in New York State through the implementation of physical projects., • The Project Engineer I works with customers to develop projects incorporating energy efficiency measures to reduce the customers' energy consumption. Job Functions & Responsibilities • Represent COMPANY at customer meetings, design meetings, contractor walk through, and presentations to customers., • Prepare engineering calculations, estimates, and cost analyses for feasibility/audit reports., • Manage and implement multiple lighting, HVAC, controls, wastewater treatment, and building envelope energy conservation projects and new project development concurrently., • Project responsibility can range from 10-15 projects depending on scope., • Develop customer installation commitment documents including cost recovery agreements requiring the development of economic analyses and engineering specifications., • Track and prepare status reports for all assigned projects., • Evaluate project scope, review feasibility reports, make presentations and recommendations, develop design documents and specifications, evaluate bid results, and make recommendations for contract award., • Develop and verify engineering, labor and material bid specifications provided by staff and implementation contractors., • Ensure that all design, code, licensing and operating and maintenance requirements are met., • Review project activities for technical content, accuracy, cost control and schedule., • Solve problems related to customer bill savings, design and construction issues. Support the Senior/Lead Project Engineer and other senior engineers in negotiating change orders to construction and services contracts., • Develop and verify all financial and billing documentation relating to savings calculations supporting the cost-effective direct install projects., • Ensure that all financial resources expended by COMPANY are fully recovered from each program participant. Evaluate all change order claims and payment invoices, while working as a team member with other engineers inside and outside of COMPANY to develop the most cost-effective project designs., • Coordinate activities between contractors / consultants / equipment vendors / customers to provide project construction quality assurance in adherence to project specifications and compliance to state and local codes., • Comply and enforce the compliance of hazardous material handling, safety and environmental procedures., • Keep abreast of the latest technological developments, products and revisions to the COMPANY project input parameters (electric Production and Delivery rates, Interest During Construction (IDC), financing term, discount rate, Gross Receipt Taxes (GRT), Contracts, Environmental and Bond Counsel). Skills • Strong knowledge of building mechanical/electrical systems and related codes is required., • Technical knowledge across multiple engineering disciplines., • Strong background and experience interacting and liaising with engineering consultants and labor contractors., • Strong project management skills with the ability to plan, execute and complete multiple projects from start to finish on time and within budget with minimal direction and support from supervisors., • Ability to work in a team-oriented environment., • Excellent interpersonal skills; good written and verbal communication skills with the ability to organize information and effectively present ideas to the intended audience., • Demonstrated ability to analyze existing conditions in a facility, and address issues related to contracts, equipment design and operation., • Ability to analyze and address environmental concerns as they relate to customer requirements and, with the guidance of more senior engineers, develop cost effective engineering solutions to non-routine problems. Ability to exercise good judgment and influence others, while working effectively with consultants, contractors, and equipment suppliers. Ability to proactively recognize problems that arise during analysis procedures or in analysis results., • Ability to further develop technical knowledge in utility service rate analyses (gas & electric), energy analysis, life cycle cost analysis, COMPANY contracts, project financing strategies, and energy systems and controls is required., • Working knowledge of SAP, Oracle Primavera, and Microsoft Teams is preferred., • Ability to travel to customer facilities (NYC Boroughs) to support construction activities as needed., • Availability to work outside of normal business hours as project demands. Education & Certifications • Bachelor's degree in Mechanical, Electrical Engineering or related engineering discipline., • Minimum of five (5) years of engineering experience., • Professional Engineer license is preferred., • Project management experience., • Professional certifications such as Project Management Professional Certification (PMPC) or Certified Energy Manager (CEM), or an advanced degree in an engineering, scientific or business discipline preferred EEO Employer LanceSoft is a certified Minority Business Enterprise (MBE) and an equal opportunity employer. We prohibit discrimination and harassment of any kind based on race, color, sex, religion, sexual orientation, national origin, disability, genetic information, pregnancy, or any other protected characteristic as outlined by federal, state, or local laws. This policy applies to all employment practices within our organization, including hiring, recruiting, promotion, termination, layoff, recall, leave of absence, compensation, benefits, training, and apprenticeship. LanceSoft makes hiring decisions based solely on qualifications, merit, and business needs at the time.

Job Description ABOUT VEG In 2014, VEG was born with a mission to help people and their pets when they need it most by challenging norms and fixing the ER experience. Since then, we've expanded rapidly, with hospitals nationwide open 24/7/365, and created an ER experience that focuses on what our pets and pet parents really need. We've done the same for our people (VEGgies), finding a way to say YES so they are empowered to achieve great things, grow in unexpected ways, and find a place where they truly belong. We're rethinking emergency care from every angle—from how we run our hospitals to how we support the people working inside them. That's where our headquarters team comes in. Whether building technology to make our hospitals more efficient, recruiting and growing incredible VEGgies, or bringing our brand to life through marketing, our VQ (VEG Headquarters) team makes it all possible—ensuring our hospitals and people have everything they need to help pets and their families. VEG is a 2025 and 2026 certified Great Place to Work®. THE JOB At VEG, we find a way to say YES–and this role brings that mindset to how we design hospitals that make a different kind of emergency care possible. As Design Project Manager, you'll combine the hands-on design of new VEG hospitals while also assisting with relocations, expansions, and renovations; seeing each project through from initial site evaluation and space planning through construction and opening. You'll turn spaces into functional, welcoming hospitals for our teams, customers, and pets. You'll develop floor plans, guide external architects and engineers, review construction documents, and keep design decisions and deliverables moving. Working cross-functionally with Real Estate, Construction, Operations, and hospital leadership, you'll balance clinical needs, customer experience, brand standards, and project schedules. You'll see your work directly help people and their pets when they need it most, find ways to bring VEG's hospital experience to life, learn from the people using it, and help make the next hospital better. WHAT YOU'LL DO • Own hospital design projects. Lead the design process primarily for new hospitals, while supporting relocations, expansions, and renovations. Manage schedules, deliverables, decisions, and approvals across multiple projects, anticipating risks and keeping work moving from site evaluation through opening., • Turn challenging spaces into functional hospitals. Evaluate existing conditions and site constraints, then develop test fits and floor plans that support clinical workflows, customer access, equipment needs, and VEG's design standards., • Bring the right people and requirements together. Guide external architects, engineers, and consultants, and partner with Real Estate, Construction, Operations, IT, Facilities, and hospital leaders to resolve competing needs and deliver coordinated designs., • Get the details right before construction. Critically review architectural and engineering documents for accuracy, coordination, and alignment with approved plans and standards. Work with architects and permitting partners to resolve gaps, review comments, and approval requirements., • Solve problems as projects become real. Partner with Construction on field conditions, requests for information, submittals, substitutions, and value-engineering decisions. Explain tradeoffs, protect essential functionality, and ensure approved changes reach the right people and documents., • Improve the next hospital through what you learn. Gather feedback from hospital teams and completed projects, and help strengthen layouts, finishes, details, specifications, and review processes so good solutions carry forward and recurring problems do not. WHAT YOU NEED • Bachelor's degree in Architecture, Interior Design, or a related field, or equivalent relevant experience. Architectural licensure or NCIDQ certification is welcome but not required., • 5+ years of experience in architectural design or design project management, including responsibility for multiple concurrent projects., • Experience delivering commercial interiors or tenant improvement projects from space planning through construction. Experience designing veterinary hospitals (or other animal care facilities) is a huge plus. Retail, restaurant, healthcare, or other repeat-location programs are particularly relevant., • Strong space-planning skills and the ability to turn operational requirements into functional, buildable layouts., • Experience coordinating external architects, engineers, vendors, and internal stakeholders., • Ability to read and critically review architectural, structural, and mechanical, electrical, and plumbing drawings., • Working knowledge of building codes, accessibility requirements, and permitting processes, with the ability to identify issues and coordinate resolution with the architect of record., • Proficiency in AutoCAD and Bluebeam; experience with Revit, SketchUp, rendering tools, and project management software is a plus., • Strong organization, attention to detail, and follow-through, with the ability to manage shifting priorities and keep decisions moving., • Clear written, verbal, and visual communication skills, including the ability to explain design recommendations to people without a design background., • Ability to travel up to 25% of the time, when needed., • Ability to be in-person at VQ (our headquarters in White Plains, NY) 4 days per week. WHO YOU ARE • Empathetic, instinctively taking a people-centric approach, whether supporting your colleagues or making an effort to understand different perspectives, • Have a sense of humility; acknowledging mistakes, sharing credit with others, and lifting up your team's' accomplishments, • Feel a strong sense of ownership over your work, taking responsibility for outcomes and staying committed to achieving long-term, impactful results, • Curious by nature; you ask insightful questions and continuously seek out opportunities to learn and grow your skills and knowledge HOW WE INVEST IN YOU • Competitive Compensation Including ($100,000 - $130,000) + bonus + benefits., • Comprehensive health and wellness benefits that start on day one, and access to free therapy or counseling., • Paid parental leave, up to 12 weeks at 100% of regular salary, and offering inclusive fertility and family-building care for all types of families., • Unlimited PTO to use for vacation or sick days—however you need it!, • Generous employee referral program, so our awesome people can bring in more awesome people., • And the little (big) things, like casual office attire, ability to bring your fur baby to work, cool VEG swag, food in the fridge for when you're hungry and free lunches twice a week!!, • Company laptop and a monthly cell phone reimbursement. BETTER TOGETHER: WHY IN-PERSON MATTERS AT VEG HQ Our hospitals thrive on in-person collaboration, and VQ is no different. Time in the office sparks stronger connections, meaningful conversations, and better results—all bringing our core values to life. We prioritize being present because our values are best achieved side by side. Plus, we make getting here easy with free parking and a shuttle from the White Plains Metro-North station. DEI At VEG, diversity is not just a word—it's a strength that fuels innovation and kindness. Our mission is "Helping people and their pets when they need it most." And we do that better when our VEGgies (employees) feel valued, respected, and empowered to bring their authentic selves to work. That's why we're devoted to creating an environment that reflects the diverse communities we serve—where different perspectives are not only welcomed but celebrated. We are focused on providing equitable opportunities for growth, promoting inclusive decision-making, and ensuring that everyone's perspective is considered. Saying yes to VEG means helping us build a culture where your unique experiences and background contribute to a shared vision: being the world's veterinary emergency company.

Job DescriptionFinal compensation will be based on a combination of: · Relevant work experience · Education · Project size · Project location · Required working hours · Candidate subject matter expertise and/or specialty · Ability to be approved by agencies/owners as required · Final salary determination is negotiable Join our "track" record of success! Recently nationally ranked as a best construction workplace by Fortune Magazine, we are looking to grow our most valuable asset … our employees! J-Track is known for its close-knit, loyal, and dedicated staff who share one mission: completing projects on-time and under budget all while fostering an environment of growth and success. Not only is J-Track the best track and transit system contractor in New York, but we also strive to maintain our reputation as a formidable force in the heavy civil construction market. We have successfully performed railroad track work, civil construction, and architectural work for a number of governments agencies engaged in public transportation. Looking to engineer a new career path? Join the J-Track family and help us lay the foundation for the future! The Scheduler's primary function is to provide strategic and CPM scheduling oversight for J-Track projects and project pursuits. You will provide schedule guidance to enable identification and verification of project timelines, sequencing including associated constraints, risks and potential resource bottlenecks. You will also work closely with our cost estimating and business development teams. Keys to success will be input on proposal schedules, project baseline schedules, schedule updates, and schedule impacts associated with Change Orders and Claims. II. EDUCATION/CERTIFICATIONS • Degree in Construction Management, Engineering, Business or other related field (or equivalent years' experience). III. KEY RESPONSIBILITIES • Develop and maintain the project's baseline Critical Path Method (CPM) schedule in Oracle Primavera P6 including Work Breakdown Structure (WBS), activity coding, calendars, resource and cost loading etc. in accordance with contract specifications and work scope., • Directly support estimating teams in initial project schedules and phasing plans for Design-Build and Design-Bid-Build Projects, • Prepare monthly updates and analyze progress against baseline, identify critical and near-critical paths, and prepare variance narratives., • Quantify the schedule impact due to change orders, delay events etc. and integrate approved changes into the CPM schedule and reconcile schedule logic., • Develop Time Impact Analysis (TIAs) in support of associated schedule impacts, • Provide guidance, direction, and specialized assistance for the resolution of difficult and complex project control problems. IV. QUALIFICATIONS OF THE POSITION • 5+ years of experience as a Scheduler or Project Controls position is required;, • Prior MTA project experience is required; Prior formal experience as an Approved Schedule Manager on MTA projects is preferred., • Advanced working proficiency in Oracle Primavera P6, including resource & cost loading, schedule risk analysis, and XML-based schedule comparison tools., • Expert in Critical path analysis and mitigation as well as network logic analysis., • Basic construction knowledge of civil, electrical, mechanical, architectural, or related construction/engineering principles., • Strong communication skills to work collaboratively with the project team., • J-Track does not offer work-from-home options. Depending on the assignment, the successful candidate will be expected to report to a project office or the main office daily. #ZR Salary Range: $115,000—$180,000 USD \nCompany Description Iovino Enterprises is the parent company to four New York City based construction companies that share a common commitment to excellence, innovation, and exceptional results. Unlock your potential and seize the opportunity to be at the forefront of a construction empire. As a product of 35 years in the construction business, we have harnessed expertise in cutting-edge technology, human capital management, finance, and legal/compliance, all while fostering an environment where each company retains its distinct personality and style. This “family of companies” culture is rooted in a common vision and set of values: respect, development for all employees regardless of position, and a commitment to give back to our communities. Iovino Enterprises is the parent company to four New York City based construction companies that share a common commitment to excellence, innovation, and exceptional results. Unlock your potential and seize the opportunity to be at the forefront of a construction empire.\r\n\r\nAs a product of 35 years in the construction business, we have harnessed expertise in cutting-edge technology, human capital management, finance, and legal/compliance, all while fostering an environment where each company retains its distinct personality and style. This “family of companies” culture is rooted in a common vision and set of values: respect, development for all employees regardless of position, and a commitment to give back to our communities.

Job Description Join the Origis Energy Team! Origis Energy is accelerating the transition to a carbon-free future by Reimagining ZeroSM. As one of America's leading renewable energy and decarbonization solution platforms, the company continues to expand and reimagine its contribution to the world's net-zero goals. Origis Energy puts customers first to deploy a wide range of sustainable solutions for grid power generation, performance optimization, and long-term operation of solar and energy storage plants across the U.S. Founded in 2008, Origis Energy is headquartered in Miami, FL. The Origis team, regarded as one of the leading developers in the U.S., is committed to living five core values in all interactions both with each other and external stakeholders: Solve for Tomorrow. A role with Origis Energy puts you at the forefront of the transition to clean energy. Are you ready to bring new ideas? Do you exist to find solutions? That's how we revolutionize energy and build a carbon-free future - through unmatched service and relentless innovation. Rise Together. To succeed here, you'll collaborate with others and work as one team, across various teams including solar and energy storage development, financing, engineering, procurement and construction (EPC) and operations, maintenance and asset management. Are you open to diverse perspectives and prepared to work seamlessly across disciplines to reach our collective goals? Perform at Peak. We're seeking team members who bring authentic energy and passion to every task. How can you use your natural strengths, genuine optimism and intelligence to make your greatest contributions to Origis? Inspire & Grow. The Origis team is comprised of knowledgeable, passionate solar and energy storage experts who bring deep expertise and solution-driven thinking to clients. A successful Origis team member encourages others and sets a high bar for growth. We have a culture of continuous improvement because each team member takes the role of both learner and mentor. Be Resilient. The spirit in which we tackle the energy challenges and objectives of our clients means we consistently stretch for the extra mile. We all take initiative and remain adaptable, overcoming obstacles by prioritizing respect. Origis Energy is seeking a finance professional for the role of Investment Associate or Manager to join our growing team. This position will assist the Company in evaluating, underwriting and managing investments in utility scale Solar and Battery Energy Storage System projects, evaluating project-level financing options, performance reporting and asset management for existing operational projects. The Investment Associate or Manager is a regular, full-time position, and is eligible for our generous employee benefits package, including employer paid health insurance, paid time off, a 401(k) plan with employer matching contributions, and other great benefits. Key Responsibilities • Investment related tasks, including:, • Excel-based project financial modeling, structuring support, ad-hoc investment analysis, • Build and maintain project financial models throughout all stages of the project lifecycle, from inception through operations, • Liaising with relevant cross-functional stakeholders (Business Development, Project Development, Engineering, O&M, Procurement, Tax, Data Science, Legal, Capital Markets) to ensure project information is accurate and consistent, • Preparation and presentation of pricing and final investment memos to the Company's Chief Executive Officer and investment committee, • Analyzing and evaluating strategic corporate M&A opportunities, • Provide modeling support and guidance to Capital Markets team on debt and tax equity project financings, • Assisting with pricing, negotiation, and evaluation of power purchase agreements (PPAs) and battery tolling agreements, with a particular focus on performance forecasting and quantifying financial impacts of risks and key terms; performing analysis of existing contracted and operating fleet to benchmark underwriting against real-time data to create a feed-back loop for process improvement, • New market research and analysis includes:, • Ability to understand key power-market trends in both regulated and deregulated power markets and how they relate to the Company's portfolio, • Providing thought leadership on commercial negotiations as well as help drive internal development priorities for optimal return on capital, • Ability to understand federal, state and local programs for renewable energy incentives and siting / tax opportunities, • Analyzing the incentive and tax environment and ability to underwrite various revenue streams, • Financial Planning & Analysis duties includes:, • Prepare detailed budgets for investment projects, reporting on budget to actuals and be responsible for cash management on relevant investment projects, • Coordinate all activities to assure a successful and timely realization of the project, • Communicate with Capital Markets, Accounting and FP&A department on changes on projects and corporate liquidity impacts of projected tax equity & back-leverage financings, • Other tasks include:, • Assist in the acquisition and sale of projects, • General support for ad hoc strategic initiatives Preferred Qualifications • Demonstrated knowledge of renewable energy power plants, • Expert financial modeling skills are essential; prior financial modeling experience (LBO, Cash Flow, Debt Sculpting), • Intimate knowledge of tax equity and project financing structures, including a deep understanding of tax equity partnership accounting (inside / outside basis), • Ideally 3+ years' experience in renewable energy development / private equity / investment banking / project finance; 2+ years' experience in renewables / solar strongly preferred, • Exposure to PPA agreements, • Base level understanding of power markets, • Bachelor's degree (MBA/CFA or Master's degree in related field preferred but not required) Key Attributes for Success • High degree of initiative and work-ethic, • Intellectual curiosity and a sincere interest in renewable energy and a passion for learning, • Proven organizational skills, ability to manage numerous unrelated tasks simultaneously, • Proven ability to deliver quality products under strict deadlines, • Ability to make evidence-based data-driven decisions, • A dedication to accountability and transparency (strong ownership mentality), • Strong problem-solving skills, • Excellent self-directed research capabilities, • Ability to work cross functionally and display emotional intelligence, • Strong team attitude, easy to get along with, willing to learn and take on new tasks, energetic about getting work done, • Critical thinker who enjoys engaging in thoughtful and respectful debate Location White Plains, New York - working from office Tuesday, Wednesday & Thursday in accordance with our in-office policy Travel Up to 10% as deemed necessary by the organization Level Associate or Manager level depending on experience and qualifications – no direct reports The expected starting pay range for this role is outlined below, in addition to a competitive annual bonus and benefits, 401K, etc. This range is an estimate and base pay may be above or below the ranges provided as our individual pay is determined by several factors including, but not limited to, location, experience, education & certifications, as well as performance. New York Pay Range $150,000—$230,000 USD Origis Energy is an Equal Opportunity Employer (EOC). All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, or protected veteran status and will not be discriminated against on the basis of disability. We are committed to fostering, cultivating and preserving a culture of diversity, equity and inclusion. We embrace and encourage our employees' differences as that is what makes our employees unique. Our management team is dedicated to this policy with respect to recruitment, hiring, placement, promotion, transfer, training, compensation, benefits, employee activities and general treatment during employment. More information is available here. California Applicants: Please review our California Privacy Policy and Notice at Collection. Request for Support or Accommodations: As part of our effort to provide equal opportunity to qualified disabled veterans and individuals with disabilities, we are happy to offer support and special accommodations in order for you to successfully reach us with your interest. Please reach out to us at candidateaccommodations@origisenergy.com if you would like to request help with your application.

Job Description Title: Project Engineer Job Summary Infinity Contracting Services Corp is actively seeking a highly motivated Project Engineer with prior construction experience to join our team to a project located in the five boroughs of New York City. We recognize our employees are the company’s most valuable asset. Inspiration, diligence, and encouragement towards each other coupled with purposeful work lead to a rewarding career, and we are proud to provide a platform with which our employees can attain their goals. The Project Engineer position will assist and support project manager, superintendent, and/or foreman on assigned project(s). The position will work under direct supervision, perform routine daily activities and gather, distribute information and deliverables, and manage project management software. Responsibilities and Duties · Setup, manage and maintain project management software for each job · Organize, maintain and process contract documents and shop drawing in order to meet project budget, schedule, and requirements · Identify, issue and manage RFIs · Formulate start-up, testing and commissioning procedures · Serve as a point of contract regarding technical information associated with the project · Verify existing field conditions and report changes to affected parties · Lead internal MEP coordination process · Facilitate required inspections, testing, and commissioning · Review contract documents for completeness and consistency · Identify project scope deviations from contract documents and field observations · Monitor construction progress for quality compliance · Resolve and manage client issued non-compliance reports · Assist the project manager with buy-outs · Release equipment and materials per approved submittals · Manage and coordinate lead times and delivery dates for equipment and material · Generate submittal, RFI, equipment, etc. logs for project stakeholders Qualifications and Skills • Bachelor’s Degree in Engineering: Mechanical, Civil, Environmental, or related engineering disciplines (or equivalent experience)- NOT REQUIRED, • 3+ years of experience on projects, • Ability to work in a multi-task environment, • Strong oral and written communication, • Excellent time management skills, • Working knowledge of Microsoft Office Suite Benefits: • 401 (k) *401 (k) matching *Dental Insurance *Health Insurance *Vision Insurance *Life Insurance *Opportunities for advancement

Job Description Temporary Job Request Number: CWP - 1534 - Electrical Designer Contingent Worker Information Position Title Electrical Designer NYPA Business Unit Utility Operations Experience Level 2 (5-10 years) Work Location White Plains Office Anticipated Start Date Immediate Duration of Assignment 12 month(s) Project/Assignment Transmission LEM CWP Manager Christine.Prendergast@nypa.gov Date of Posting 10/23/2026 Due Date 11/07/2026 Work Schedule Monday through Friday. 7.5-hour workday with .5-hour unpaid lunch. Paid for actual time worked; there are no paid vacation or sick days. During NYPA and Canals holidays, the business is closed, and no work is permitted. NYPA requires a hybrid schedule of a minimum of 4 days on-site, up to including fully on-site depending on department requirements. CWPO Engagement Requirements Candidates are REQUIRED to be local to Tri-State area and in W2 tax status as employee of Service Provider. Fully remote positions are prohibited. Hybrid schedules are permissible with a minimum of 3 days on-site depending on assignment and can be fully on-site depending on business needs. Remote work privileges can be revoked at any time. NYPA does not provide laptops. Instead, NYPA provides desktops and dedicated workstations which candidates will remote into from their personal equipment on virtual days. If candidate does not have proper equipment, internet connection, or he/she is deemed to not work effectively from home, the hybrid privilege will be revoked. Vendors must disclose foreign national status and all Visas at the time of candidate submission. Additionally, a Benefits Waiver and Ethics Disclosure will be required by all candidates during onboarding. Submission Instructions • The LEGAL name of candidate (no aliases, monikers, or nicknames), • Job Broadcast number in your email subject header, • Visa work authorization, if applicable, • For job broadcasts outside your contractual compensation schedules, use competitive rates based on local and state compensation., • NYPA CWP staff will contact you if your candidate is selected to be interviewed, which is usually via MS Teams. Please inform your candidates that an interview does not indicate acceptance of the proposed labor rates., • For all questions or concerns, please contact Christine Prendergast at Christine.Prendergast@nypa.gov or Markus Caruso at Markus.Caruso@nypa.gov. Project Overview Transmission and Generation upgrade projects at the various generation facilities. Job Functions & Responsibilities An Electrical Designer (Physical) performs calculations and prepares the most complex design packages for construction utilizing technical specifications, design criteria and industry codes and standards. • Independently prepares the most complex drawings and/or schematic diagrams/block diagrams, cable & conduit schedules/flow diagrams/equipment layouts/foundation details/plan and profiles/structural details/P&IDs/bill of materials, etc. specific to their design discipline., • Evaluates budgetary and schedule constraints and provides design alternatives to the Design Supervisor., • Able to quickly recognize issues that could arise during the design development process and ensure they are avoided., • Confirms final drawings prepared by other Designers are accurate and technically complete and in accordance with regulations and applicable design standards., • Works with the sites to ensure that record drawings are in accordance with configuration management policies and procedures., • Coordinates design efforts with the Engineers and fellow Senior Designers on multi-disciplined tasks. Skills • Superior technical expertise in design discipline. Extensive working knowledge and experience in engineering principles, construction techniques and exceptional design & drafting practices., • Superior AutoCAD and Raster Design skills. Ability to effectively use drawing management systems such as AutoCAD Vault, • Excellent knowledge of related design disciplines and their interaction in the design process., • Demonstrated ability to view tasks logically and determine essential requirements., • Can generate a design solution utilizing accepted standards and codes., • Ability to handle multiple tasks and multi-phase projects., • Independently expedite work with changing priorities., • Ability to solve the most complex technical problems quickly and able to recognize issues that arise early in the design process to maintain schedule and deliverables., • Highly effective oral communication skills are required to provide detailed technical topics to other team members., • Advanced written communication skills are required to report clear, concise technical details., • Demonstrate flexibility in changing project requirements, priorities and assignments. Education & Certifications • Associate degree or 2 years' additional experience., • Minimum of 2 years of applicable industry related experience

Job Description Temporary Job Request Number: CWP - 1525 - Project Engineer Contingent Worker Information Position Title Project Engineer NYPA Business Unit Utility Operations HQ Experience Level 1 (1-5 years) Work Location White Plains Office Anticipated Start Date Immediate Duration of Assignment 12 month(s) Project/Assignment Direct Install Lighting Program CWP Manager Date of Posting 10/09/2026 Due Date 10/24/2026 Work Schedule Monday through Friday. 7.5-hour workday with .5-hour unpaid lunch. Paid for actual time worked; there are no paid vacation or sick days. During NYPA and Canals holidays, the business is closed, and no work is permitted. NYPA requires a hybrid schedule of a minimum of 3 days on-site, up to including fully on-site depending on department requirements. CWPO Engagement Requirements Candidates are REQUIRED to be local to the Tri-State area and in W2 tax status as an hourly paid employee of Service Provider. Fully remote positions are prohibited. Hybrid schedules are permissible with a minimum of 3 days on-site depending on assignment and can be fully on-site depending on business needs. Remote work privileges can be revoked at any time. NYPA does not provide laptops. Instead, NYPA provides desktops and dedicated workstations which candidates will remote into from their personal equipment on virtual days. If candidate does not have proper equipment, internet connection, or he/she is deemed to not work effectively from home, the hybrid privilege will be revoked. Vendors must disclose foreign national status and all Visas at the time of candidate submission. Additionally, a Benefits Waiver and Ethics Disclosure will be required of the candidate during onboarding. Submission Instructions Your email submissions must contain: The LEGAL name of candidate (no aliases, monikers, or nicknames) Job Broadcast number in your email subject header Visa work authorization, if applicable For job broadcasts outside your contractual compensation schedules, use competitive rates based on local and state compensation. NYPA CWP staff will contact you if your candidate is selected to be interviewed, which is usually via MS Teams. Please inform your candidates that an interview does not indicate acceptance of the proposed labor rates. For all questions or concerns, please contact Christine Prendergast at or Markus Caruso at . Project Overview The Project Engineer Isupports the Customer Project Delivery department in achieving the Business Unit's goals to improve energy efficiency and stimulate new energy technologies in New York State through the implementation of physical projects. The Project Engineer I works with customers to develop projects incorporating energy efficiency measures to reduce the customers' energy consumption. Job Functions & Responsibilities • Represent NYPA at customer meetings, design meetings, contractor walk through, and presentations to customers., • Prepare engineering calculations, estimates, and cost analyses for feasibility/audit reports., • Manage and implement multiple lighting, HVAC, controls, wastewater treatment, and building envelope energy conservation projects and new project development concurrently., • Project responsibility can range from 10-15 projects depending on scope., • Develop customer installation commitment documents including cost recovery agreements requiring the development of economic analyses and engineering specifications., • Track and prepare status reports for all assigned projects., • Evaluate project scope, review feasibility reports, make presentations and recommendations, develop design documents and specifications, evaluate bid results, and make recommendations for contract award., • Develop and verify engineering, labor and material bid specifications provided by staff and implementation contractors., • Ensure that all design, code, licensing and operating and maintenance requirements are met., • Review project activities for technical content, accuracy, cost control and schedule., • Solve problems related to customer bill savings, design and construction issues. Support the Senior/Lead Project Engineer and other senior engineers in negotiating change orders to construction and services contracts., • Develop and verify all financial and billing documentation relating to savings calculations supporting the cost-effective direct install projects., • Ensure that all financial resources expended by NYPA are fully recovered from each program participant., • Evaluate all change order claims and payment invoices, while working as a team member with other engineers inside and outside of NYPA to develop the most cost-effective project designs., • Coordinate activities between contractors / consultants / equipment vendors / customers to provide project construction quality assurance in adherence to project specifications and compliance to state and local codes., • Comply and enforce the compliance of hazardous material handling, safety and environmental procedures., • Keep abreast of the latest technological developments, products and revisions to the NYPA project input parameters (electric Production and Delivery rates, Interest During Construction (IDC), financing term, discount rate, Gross Receipt Taxes (GRT), Contracts, Environmental and Bond Counsel). Skills • Strong knowledge of building mechanical/electrical systems and related codes is required., • Technical knowledge across multiple engineering disciplines., • Strong background and experience interacting and liaising with engineering consultants and labor contractors., • Strong project management skills with the ability to plan, execute and complete multiple projects from start to finish on time and within budget with minimal direction and support from supervisors., • Ability to work in a team-oriented environment., • Excellent interpersonal skills; good written and verbal communication skills with the ability to organize information and effectively present ideas to the intended audience., • Demonstrated ability to analyze existing conditions in a facility, and address issues related to contracts, equipment design and operation., • Ability to analyze and address environmental concerns as they relate to customer requirements and, with the guidance of more senior engineers, develop cost effective engineering solutions to non-routine problems., • Ability to exercise good judgment and influence others, while working effectively with consultants, contractors, and equipment suppliers., • Ability to proactively recognize problems that arise during analysis procedures or in analysis results., • Ability to further develop technical knowledge in utility service rate analyses (gas & electric), energy analysis, life cycle cost analysis, NYPA contracts, project financing strategies, and energy systems and controls is required., • Working knowledge of SAP, Oracle Primavera, and Microsoft Teams is preferred., • Ability to travel to customer facilities (NYC Boroughs) to support construction activities as needed., • Availability to work outside of normal business hours as project demands. Education & Certifications • Bachelor's degree in Mechanical, Electrical Engineering or related engineering discipline., • Minimum of five (5) years of engineering experience., • Professional Engineer license is preferred., • Project management experience., • Professional certifications such as Project Management Professional Certification (PMPC) or Certified Energy Manager (CEM), or an advanced degree in an engineering, scientific or business discipline preferred.

Job Description Job Title: Assistant Project Manager 1 Who we are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. Summary/Objective: The Assistant Project Manager (APM 1) will serve as a vital team member assisting the Senior Project Manager/Project Manager on the full scope of the project. The APM 1 will be responsible for Document Control & Procurement Management, Communication, Cost Management, Subcontractor Coordination and Project Reporting while representing Callahan Construction Managers throughout the full project cycle. The APM 1 will also have oversight in managing the Project Administrators on task completion. The APM must exhibit time management skills and prioritize their work based on the daily needs of the project. Essential Functions: Safety -Coordination of Safety Program compliance in conjunction with the Superintendent -Shadow Safety Inspectors on site visits -Conduct 4 (minimum) independent safety inspections per month -Assist / Participate in all safety related activities and always promote a safety culture Document Control & Procurement Management -Understand the Plans, Specifications and Contracts of the project -Review of shop drawings and samples for compliance with contract documents -Coordination of meetings with Owners / Architect / Engineer and producing quality meeting minutes and meeting package content all in a timely manner -Manage all RFIs and Submittals utilizing Viewpoint with consultants, subcontractors, and field staff -Manage updates of the current construction document set utilizing Procore -Distribute information to subcontractors/suppliers -Reviewing and tracking material deliveries as scheduled and expediting in conjunction with the Project Superintendent to ensure on-time procurement Communication -Develop and maintain positive relationships with the Owner, Subcontractors and Project Team -Coordinate and communicate updates and changes to the schedule of the project. -Control the prompt flow of information to field team, subcontractors, and suppliers Cost Management -Participate in subcontractor buyout and subcontract issuance -Compile all changes in the project. Vet pricing on all change requests and submit proposals with time extensions as needed; Reviewing with Project Manager prior to submission. -Proficient in project accounting processes to ensure prompt payments of requisitions & Invoices -Review of monthly Subcontractor requisition and material invoices with your manager -Compile field tickets from Superintendent and attach to all material invoices processed Project Management and Reporting -Distribute Punchlist for execution -Participate in the monthly schedule update meeting -Preparing and submitting of the “Monthly Report” to the project team with guidance from your manager and Superintendent -Preparation of Quarterly cost meetings -Competing the Closeout of the project with the Owner and Subcontractors -Compile permit closeout and turnover documents -Maintain all records and files -Operations and Maintenance Manuals -Financial Closeout with PM and Accounting People Management -Oversee the Project Administrator tasks which include compliance log, subcontractor insurance, subcontractor change proposal tracking, subcontractor change order execution, EEO/MBE/WBE Required education and experience: -Bachelor’s Degree (Preferably Engineering, Construction Management or Architecture) -0-5 Years experience -Prior experience in construction settings All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color religion, sex, sexual orientation, gender identity, national original or on an applicant’s status as a protected veteran or as individual with a disability.

Job Description Join the Origis Energy Team! Origis Energy is accelerating the transition to a carbon-free future by Reimagining ZeroSM. As one of America's leading renewable energy and decarbonization solution platforms, the company continues to expand and reimagine its contribution to the world's net-zero goals. Origis Energy puts customers first to deploy a wide range of sustainable solutions for grid power generation, performance optimization, and long-term operation of solar and energy storage plants across the U.S. Founded in 2008, Origis Energy is headquartered in Miami, FL. The Origis team, regarded as one of the leading developers in the U.S., is committed to living five core values in all interactions both with each other and external stakeholders: Solve for Tomorrow. A role with Origis Energy puts you at the forefront of the transition to clean energy. Are you ready to bring new ideas? Do you exist to find solutions? That's how we revolutionize energy and build a carbon-free future - through unmatched service and relentless innovation. Rise Together. To succeed here, you'll collaborate with others and work as one team, across various teams including solar and energy storage development, financing, engineering, procurement and construction (EPC) and operations, maintenance and asset management. Are you open to diverse perspectives and prepared to work seamlessly across disciplines to reach our collective goals? Perform at Peak. We're seeking team members who bring authentic energy and passion to every task. How can you use your natural strengths, genuine optimism and intelligence to make your greatest contributions to Origis? Inspire & Grow. The Origis team is comprised of knowledgeable, passionate solar and energy storage experts who bring deep expertise and solution-driven thinking to clients. A successful Origis team member encourages others and sets a high bar for growth. We have a culture of continuous improvement because each team member takes the role of both learner and mentor. Be Resilient. The spirit in which we tackle the energy challenges and objectives of our clients means we consistently stretch for the extra mile. We all take initiative and remain adaptable, overcoming obstacles by prioritizing respect. Position Description Origis Energy is seeking a midlevel attorney with 7+ years of experience in construction, procurement and O&M services for the solar and energy storage industry. The Senior Counsel, EPC & Services position will assist Origis in the preparation and negotiation of engineering, procurement and construction (EPC), equipment supply, operations and maintenance, and related agreements. This position will also support resolution of disputes related to such agreements from time to time. This position reports to the Managing Director Legal & General Counsel, is a regular, full-time position, and is eligible for our generous employee benefits package, including employer paid health insurance, paid time off, a 401(k) plan with employer matching contributions, and other great benefits. Key Responsibilities • Structuring, negotiating, reviewing, drafting, and revising term sheets, agreements, and related documents for EPC Agreements, various types of equipment supply agreements, and operations and maintenance agreements., • Advising and supporting Origis' construction, procurement and services business teams to achieve business goals and ensure compliance with internal corporate, finance and policy matters., • Drafting and reviewing change orders, lien waivers, estoppels and similar instruments., • Help ensure procurement, construction and O&M services matters are executed on schedule to support project timelines, budgets and commercial operations., • Monitor legal developments impacting procurement efforts, including with respect to trade and tariffs, executive orders, and tax credit matters such as Foreign Entity of Concern (FEOC) and prevailing wage and apprenticeship requirements, and advise the business with respect to the same., • Providing summaries of deal terms, including identification of risk factors, to senior leadership and other internal and external stakeholders., • Coordinating and overseeing work performed by outside counsel on a cost-effective basis., • Assisting other members of the legal team as needed in a variety of transactions and other matters. Preferred Qualifications • 5+ years' experience in renewable energy construction, equipment procurement, and operations and maintenance in a legal capacity., • Broad cross-functional understanding of renewable energy industry and project finance., • Prior in-house or law firm experience preferred, especially in renewable energy and infrastructure., • Experience with various forms of dispute resolution, including litigation, arbitration and mediation., • Experience identifying legal issues and balancing against business risks in support of overall company goals., • Experience effectively collaborating with multiple stakeholders., • Record of completing assigned tasks on time while communicating frequently and appropriately with supervisors to ensure alignment., • Strong communication skills across company functions., • JD and current member in good standing of at least one state bar. Key Attributes for Success • Ability to balance legal risk with business priorities in a fast-paced environment., • Proven ability to collaborate across legal, finance, and executive teams., • Background and familiarity with solar, renewables and energy storage space., • Experience negotiating, reviewing, drafting, and revising commercial agreements under tight deadlines., • Proactive, solution-oriented mindset with strong attention to detail., • Recognized strong team player, taking the initiative supporting others, as necessary and appropriate., • Excellent written and verbal communication skills., • Superb attention to detail, as well as organizational and multitasking skills. Location In-office in Austin, TX or White Plains, NY preferred; will consider strongly qualified remote candidates Travel Occasional (< 10%) travel required as necessary Job Level Manager – no direct reports The expected starting pay range for this role is outlined below, in addition to a competitive annual bonus and benefits, 401K, etc. This range is an estimate and base pay may be above or below the ranges provided as our individual pay is determined by several factors including, but not limited to, location, experience, education & certifications, as well as performance. New York Pay Range $180,000—$240,000 USD Origis Energy is an Equal Opportunity Employer (EOC). All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, or protected veteran status and will not be discriminated against on the basis of disability. We are committed to fostering, cultivating and preserving a culture of diversity, equity and inclusion. We embrace and encourage our employees' differences as that is what makes our employees unique. Our management team is dedicated to this policy with respect to recruitment, hiring, placement, promotion, transfer, training, compensation, benefits, employee activities and general treatment during employment. More information is available here. California Applicants: Please review our California Privacy Policy and Notice at Collection. Request for Support or Accommodations: As part of our effort to provide equal opportunity to qualified disabled veterans and individuals with disabilities, we are happy to offer support and special accommodations in order for you to successfully reach us with your interest. Please reach out to us at candidateaccommodations@origisenergy.com if you would like to request help with your application.

Job Description About E-J: The E-J Group is active in all facets of electrical contracting, bringing experience, expertise, and a national reputation to projects that range in size up to more than $300 million. With over 4,500 employees across 33 offices, E-J delivers full-service electrical solutions for rail systems, transit facilities, office buildings, hospitals, power, renewable energy, clean energy, co-generation facilities, roadway and outdoor specialty work, airports, industrial facilities, data centers, chip plants, universities, sports stadiums, extra high voltage distribution, utility, and gas infrastructure. At E-J, three generations of family expertise have built an organization that combines practical knowledge with modern technological innovation, providing rapid and efficient solutions for today’s lighting, power, energy, and communication needs. E-J has over a 125-year reputation for integrity, quality, and exceptional service in the electrical field. To learn more, visit www.ej1899.com. Title/Role: Draftsperson Division: Engineering Location: Port Washington, NY Reporting to: Engineering Manager Position Summary: Join E-J's growing Engineering team and build a career with one of the nation’s fastest growing contractors. As part of E-J's Engineering team, you'll work alongside experienced engineers on high-profile projects nationwide, ranging from commercial buildings, to data centers. E-J is seeking an individual proficient in Revit, AutoCAD MEP and Navisworks. You will be responsible for modeling, and producing design drawings, layouts, and sketches in accordance with project specifications and direction of the project team. You will support the development of documentation needed for construction and prefabrication. You will collaborate with project engineers and managers to align with project deliverables. What You’ll Do: • Assist the Engineering staff with project deliverables to keep pace with the project schedule, • 3D modeling of electrical systems in REVIT per the direction of the Project Engineer, • Create shop drawings and sketches based on the existing model, • Makes changes to existing drawings and models based on comments from the project team, • Create prefabrication drawings to support fast-paced project delivery schedulesQualifications & Skills:, • Highly motivated team player, • 1-5 years of experience in a related field or industry, • Proficient in Autodesk products such as Revit, AutoCAD, and Navisworks, • Have basic Construction knowledge and eagerness to learn more. Electrical experience is a plus, • Proficient in MS Office Suite Advantages of Working at E-J: • Leading Electrical Contracting Organization Nationwide, • Oldest Family-Owned and Operated Electric Contractor since 1899, • Job training and mentorship, • Competitive compensation packages, • Comprehensive benefits, including medical, dental, and 401K plan, • Paid holidays and vacation, • Merit-Based Bonus, • Tuition Reimbursement ProgramSalary Range: $65k-$85k/year The E-J Group is an Equal Employment Opportunity Employer and ensures equal employment opportunity for all persons without discrimination on the basis of race, color, religion, sex, sexual orientation, national origin, age, disability, marital status, citizenship, or any other characteristic protected by law. Powered by JazzHR xweiGWQYTu

Job DescriptionCompany Description Veolia in North America is the top-ranked environmental company in the United States for three consecutive years, and the country’s largest private water operator and technology provider as well as hazardous waste and pollution treatment leader. It offers a full spectrum of water, waste, and energy management services, including water and wastewater treatment, commercial and hazardous waste collection and disposal, energy consulting and resource recovery. Veolia helps commercial, industrial, healthcare, higher education and municipality customers throughout North America. Headquartered in Boston, Veolia has more than 10,000 employees working at more than 350 locations across North America. Job Description Position Purpose: Reporting to and assisting the Veolia Water New York, Inc. Vice President of Operations , this position is responsible for the overall management of the Production and Transmission and Distribution System (T&D) for Veolia Water Westchester, Inc. (VWWC). This individual will provide managerial oversight to the operations, maintenance and construction activities in the Production and the Transmission and Distribution (T&D) Departments to ensure the following objectives are met: departmental financials as they relate to both the budget and approved rate of returns, regulatory compliance, safety, employee development, customer experience, and continuous improvement. This individual is also responsible for managing external relations with municipal and community leaders. • Revenue - $70 M, • Annual Budget - $32 M, • Capital Budget - $30 M, • Customers – 48,000, • Population Served – 200,000, • Direct Reports – 2 (Manager of Production and Superintendent of T&D), • Indirect Reports – 62 (non-exempt, non-bargaining and bargaining), • Budget Accountabilities Primary Duties/Responsibilities: • Support the Vice President of Operations of the NY Division by developing policy and strategies for VWWC, specifically non-revenue water and asset management., • Provide direction and management to ensure that VWWC operates in compliance with updated management practices, with data and record retention for auditable trails. Ensure all staff follows Veolia policies and manuals., • Direct all the statutory and regulatory requirements for health and safety to provide a safe and efficient place of work for our employees. Assist theVice President of the NY Division in providing customers with safe, reliable and adequate service in the most cost effective way., • Maintain compliance with all company, governmental and/or environmental regulations and policies to provide safe potable water., • Direct the collection of sufficient data to manage risk and make effective management decisions., • Conduct appropriate performance reviews to drive results and demonstrate continuous improvement in water treatment, water transmission, construction and distribution., • Participate in the preparation of accurate and realistic annual operating and capital plans. Monitor Key Performance Indicators., • Assists in the control of operating and capital expenditures pursuant to the time and monetary schedules contained in the plans., • Review and analyze non-revenue water statistics, determine appropriate plans and implement agreed recommendations., • Directs the operations team to ensure the attainment of service, financial goals and major program efforts., • Ensures the training and cross training of employees through on the job training workshops or schools, evaluation or appraisals, to equip them to perform their assigned duties efficiently and effectively., • Oversee laboratory process including sampling and testing., • Assist in employee and career development programs, through ongoing education, seminars and in-house training., • Participate in labor relations issues including negotiations, grievance, and arbitrations., • Work with the Regional President of the NY Division with respect to community relations by attending meetings with mayors and town administrators., • Conduct special studies or analysis as requested by the Vice President of Operations of the NY Division., • Oversees the Company's fleet maintenance and fleet leasing program., • May provide testimony in liability and litigation cases., • Responsible for documenting, developing and maintaining Company's "Emergency Response Plan"., • Keep current with Federal, State and local health regulations., • Assist with rate case filing including data collection, interrogatories, and testimony., • Advise, direct and recommend work plan for the long-term main replacement program., • Direct water treatment, water transmission, construction/distribution related budget items., • Direct all personnel in stations to ensure proper operating procedures are maintained., • Ensure timely response to customer water quality inquiries and complaints., • Direct SCADA operation., • Participate in the due-diligence process for new business ventures. Includes operations, workforce plans, and customer service. Support, direct, assume responsibility as required for integration of new operations into the NY Division portfolio. Work Environment: • Office environment.Qualifications Education/Experience/Background: • BS degree in engineering, business administration, or other management is desired or equivalent work experience., • 7 – 10 years of experience with at least five (5) years experience in a supervisory role., • Experience in various phases of utility operations, construction, engineering and customer service., • Thorough understanding of water utility construction and water treatment., • Experience in a unionized work environment is preferable., • Knowledge of water treatment methods, distribution system operations and maintenance, Utility accounting systems and procedures. Knowledge/Skills/Abilities: • Proficient Computer Skills including MS Office Suite., • Excellent Communications Skills both verbal and written. Ability to communicate clearly., • Excellent Leadership Skills including decision making and planning skills., • Excellent managerial and supervisory abilities, effective negotiating., • Organizational Skills., • Project Management Skills., • Interpersonal Skills., • Performance management., • Required to work under pressure and work on stand-by (24 hr stand-by approximately every 5 weeks). Physical Requirements: • Must be able to sit at a computer for long periods of time. Additional Information Pay Range: $145000 to $160000 Per Year. Benefits: Veolia’s comprehensive benefits package includes paid time off policies, as well as health, dental, vision, life insurance, savings accounts, tuition reimbursement, paid volunteering and more. In addition, employees are also entitled to participate in an employer sponsored 401(k) plan, to save for retirement. We are an Equal Opportunity Employer! All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, disability or protected veteran status. Disclaimer: The salary, other compensation, and benefits information is accurate as of the date of this posting. The Company reserves the right to modify this information at any time, subject to applicable law.

Job Description Hudson Meridian Construction Group (HM), a leading New York-area construction management firm, is seeking an experienced MEP Project Manager to oversee the sophisticated mechanical, electrical, and plumbing systems that define our most complex construction projects. This role is designed for a construction professional who is also a technical expert, excelling at the intersection of pre-construction strategy, field execution, and stakeholder alignment. The successful candidate will be responsible for ensuring that the "technical core" of our builds meets the highest standards of efficiency, safety, and innovation. Core Responsibilities • Technical Stewardship: Lead the end-to-end management of HVAC, Electrical, Plumbing, and Fire Protection (MEP/FP) systems, ensuring seamless integration with structural and architectural designs., • Operational Excellence: Drive the coordination process to mitigate risks and resolve spatial conflicts well ahead of installation., • Financial & Contractual Oversight: Manage high-value MEP subcontracts, including detailed scope analysis, budget forecasting, and change management., • Commissioning & Quality: Oversee the rigorous testing and commissioning phases to ensure all systems perform to design intent and regulatory requirements. Professional Qualifications • Extensive Experience: A minimum of 8–10 years in MEP project management, with a proven portfolio in large-scale commercial, institutional, or healthcare sectors., • Academic Foundation: A Bachelor’s degree in Mechanical/Electrical Engineering, Construction Management, or a related technical discipline., • Strategic Mindset: Exceptional ability to lead multi-disciplinary teams and communicate complex technical challenges to non-technical stakeholders., • Industry Proficiency: Expert-level understanding of local building codes, LEED standards, and modern construction technologies. Willingness to travel to and across the construction sites. Project Manager Candidates will possess the ability to interpret architectural plans and specifications. Positions will require scheduling, purchasing, estimating, as well as management of personnel, vendors, and subcontractors. Candidates must be proficient with computers and familiar with Microsoft Office & CMiC. Qualified candidates must be able to effectively communicate with all levels of the organization. Position is available immediately. \nCompany Description Hudson Meridian Construction Group is one of the leading construction services firms in the Northeast, offering a unique blend of expertise to private and public sector clients. Our team delivers tailored services as Construction Managers, Program Managers, and General Contractors, bringing a commitment to excellence, collaboration, and client-focused solutions on every project. Hudson Meridian Construction Group is one of the leading construction services firms in the Northeast, offering a unique blend of expertise to private and public sector clients. Our team delivers tailored services as Construction Managers, Program Managers, and General Contractors, bringing a commitment to excellence, collaboration, and client-focused solutions on every project.

Job Description Job Title: M/E/P Manager Employment Type: Full-Time FSLA: Salary/Exempt Division: Project Services Group Department: Mechanical/Electrical/Plumbing (M/E/P) Reports to: Director of M/E/P Services Supervisory Duties: Yes Salary Range: $150,000 - $180,000 The M/E/P Manager provides technical expertise in Mechanical, Electrical, Plumbing, and Fire Protection (MEP/FP) engineering. This individual serves as a subject matter expert for both internal and external stakeholders by identifying constructability issues, contributing to project schedules, overseeing commissioning efforts, and supporting the successful delivery of MEP/FP systems across all phases of construction. Responsibilities / Essential Functions • Provide MEP/FP technical oversight from preconstruction through closeout., • Review and coordinate MEP/FP design documents for constructability and system integration., • Participate in design and coordination meetings with consultants, owners, and project teams., • Evaluate subcontractor proposals, scopes of work, and prequalification packages., • Monitor MEP construction progress and ensure work aligns with plans, specifications, and code requirements., • Support the development of MEP schedules and sequencing in coordination with project teams., • Review and track MEP submittals, RFIs, and change orders., • Coordinate field inspections, startup, and testing/commissioning of MEP/FP systems., • Collaborate with commissioning agents to verify system performance and documentation., • Troubleshoot MEP system issues and work with subcontractors to resolve them., • Assist in evaluating MEP-related cost impacts, value engineering options, and project risks., • Serve as a technical resource and mentor to project team members and field personnel. Key Skills, • Ability to work on multiple projects or tasks at once., • Outstanding attention to detail., • Proactive and innovative problem solver., • Ability to excel in a fast-paced environment., • Team player that can interact with all project team members, subcontractors, field staff, and clients., • Clear and effective communicator.Requirements, • Bachelor’s degree in Mechanical Engineering or a related field., • 5–10 years of experience in the construction industry., • 5+ years of experience with M/E/P design, commissioning, and construction.

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Field Operations Department: Field Operations Reports to: General Superintendent Supervisory Duties: Yes Salary Range: $167,000 - $225,000 Reporting to the General Superintendent, the Senior Superintendent provides overall administrative and technical management of the construction project. The Senior Superintendent manages all on site construction activities including self-perform labor, subcontractors and consultants to successfully execute large and complex projects. Responsibilities / Essential Functions • Administer project safety program to maintain a safe and healthy work environment., • Proficient in all five areas of focus on their project:, • Safety, Schedule, Cost, Quality, and creating Raving Fans with all external partners., • Develop and implement a site-specific safety plan for each project assigned., • Verify that all subcontractors have a valid subcontract and an acceptable insurance certificate prior to working on site., • Serve as the OSHA competent person for various tasks or assign others to serve as competent person., • Preplan all operations to produce innovative and efficient methods to avoid hazards. Senior Superintendent must correct all recognized hazards immediately., • Supervise construction effort to ensure project is constructed in accordance with the plans and specifications., • Thoroughly understand the contract (owner/subcontractor), owner requirements, contract plans, contract specifications, submittals and any change documents, • Provide technical assistance on the project, interpret contract drawings and submittals, and develop construction methods consistent with contract documents., • Work with the project team to set project goals and schedule milestones., • Coordinate all required labor, equipment, small tools, permanent materials, and supplies as needed for self-perform operations., • Create the Site-Specific Quality Plan (SSQP), manage all aspects of project quality efforts., • Complete onsite material verification as required for the project., • Manage project budget requirements:, • Assist the Project Manager in developing budgets and monthly costs to complete., • Manage T&M process, including verification of time and materials., • Track production and submit quantities weekly., • Identify changes in the field, authorize field change requests, provide all documentation required to ensure compensation for all work performed., • Assist in the approval process for all subcontractor requisitions., • Manage the project to meet schedule requirements and milestones., • Develop a baseline schedule with Project Services Group., • Track progress against baseline schedule and critical path dates., • Communicate schedule requirements at weekly subcontractor meetings., • Develop a short-term plan on a weekly basis that directly supports the project schedule and looks ahead a minimum of 3 weeks., • Coordinate and lead the daily stand up and weekly foreman meetings., • Ensure that the material delivery log is updated and accurate., • Interface with client representatives, A-E representatives, other contractors, and various building officials in a professional manner., • Participate in business development. Create Raving Fans on current projects. Utilize contacts to initiate leads for future projects., • Participate in quarterly Superintendent and Safety meetings, as well as periodic training sessions., • Supervise assigned Foremen, Assistant Superintendents, and Project Engineers. Key Skills • Self-starter with ability to set goals and tasks with strong leadership skills., • Strong communication skills. Required Experience • Bachelor’s degree required, preferred in Construction Management/Civil Engineering., • 3-7 years of experience in the construction or related field in a similar role or 7-10 years in a supervisory role as a tradesperson., • Understands building plans and specifications., • Safety standards knowledge and enforcement, OSHA 30 required.

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Project Management Department: Project Management Reports to: Project Manager Supervisory Duties: Yes Salary Range: $85,000.00 - $124,000.00 The Assistant Project Manager (APM) will serve as a vital team member while assisting the Senior Project Manager and/or Project Manager on all aspects of a project. APM’s will be expected to take on central roles for the oversight of the Project Engineer with a specific focus on document control (RFIs, submittals, material delivery, etc.), subcontractor coordination, design team communication, project reporting and overall representation of Consigli throughout the entirety of the project. Responsibilities / Essential Functions • Serve as a main point of contact for communication with Owners, OPMs and Design Teams members., • Coordinate and provide input during weekly meetings with subcontractors, design teams, and owner representatives to resolve field conflicts and drive resolution., • Support project cost and change management process: prepare reports for review with other team members and present at both Owner and internal meetings., • Assist in development of estimates and bid proposals for both lump sum and GMP projects., • Oversight/Management of Project Engineer and associated responsibilities including document Control, RFIs, Submittals, Material Delivery Tracking and Meeting Minutes., • Mentor: support, develop, and train supporting team members, including Project Engineers., • Maintain close relations with subcontractors, including early notification of submittal & material delivery schedule expectations., • Monitor executed subcontracts and insurance certificates; verify contracts and insurance are in place prior to commencing work., • Coordinate with Project Scheduler to update and distribute project master schedule with input from Superintendent and project team., • Assist the project Superintendent and other team members in the resolution of all critical issues, RFI’s, etc. with a focus on quality, cost and schedule; provide documentation as necessary., • Take ownership of the closeout process: complete and implement project closeout checklist., • Manage close-out documentation (as-builts, O&Ms, warranties, test reports, etc.) for submission to Design Team and Owner., • Manage financial closeout process with subcontractors and Owner., • Punch List: Upload and distribute the punch list through Procore to subcontractors., • Assist with coordinating work completion as required and maintain an accurate log of items to be completed., • Observations and Field Reports: work with project team to conduct field walks as necessary and compile any corresponding documentation accordingly. Review Design Team field reports and work with required parties to resolve open items and drive to resolutions., • Safety: perform regular safety walks with field and safety staff and record observations. Key Skills, • Strong communication skills., • Ability to review, understand and support all change management processes., • Strong initiative and problem-solving abilities., • Ability to multi-task and self-prioritize., • Motivated and driven., • Ability to work in a team environment with a primary focus on collaboration., • Excellent written and verbal presentation skills. Required Experience • A bachelor's degree in engineering, Construction Management or Architecture preferred., • 3 - 5 years’ experience within the construction industry in project management or similar role., • OSHA 10 and OSHA-30 preferred., • Additional proficiencies may include cost management software (Timberline, Sage preferred), scheduling software (Primavera P6 preferred) and construction management software (Procore preferred).

Job Description Reports to: Operations Manager Department: Engineering and Maintenance Classification: Exempt, salaried Typical schedule: Tuesday through Saturday, with on call availability for emergencies Last reviewed: September 2026 About Us The Royal Regency Hotel is a family owned and operated boutique hotel in Yonkers, New York. Our mission is to cultivate an atmosphere that is warm, engaging and fun, allowing our guests to create their own distinctive memories. As a Greek American family, we take great pride in our heritage. Perhaps our most self defining concept is that of Filoxenia, or hospitality. Our greatest satisfaction comes from making our guests feel at home during their stay. Position Summary The Facilities & Maintenance Manager oversees the safe, efficient, and responsible operation of all building systems and equipment, and leads the maintenance team. This position directs the repair and maintenance of the hotel's physical assets, keeping the property in compliance with state and local requirements and meeting our standards for quality, cleanliness, guest satisfaction, safety, and security. The Facilities & Maintenance Manager runs equipment inspection and monitoring routines, sets maintenance practices, and continuously evaluates how the property is maintained and operated. Essential Functions - Property and systems • Carry out regular inspections of the facility to identify areas requiring attention, and coordinate the maintenance team to correct issues promptly., • Be familiar with all major shut off stations including water, electric, sprinkler, and fire alarm., • Plan and oversee all repair and installation activity on the property., • Provide oversight of outside maintenance contracts covering major systems, including elevators, fire alarm, boilers, HVAC, and waste disposal., • Locate and correct heating, ventilation, air conditioning and packaged terminal air conditioning malfunctions, including system and control checks, and repair or replace units as needed., • Perform and direct general upkeep across guest rooms and common areas, including plumbing repair and replacement, and minor repairs to tile, wallboard, paint, wall vinyl, carpentry, and carpet., • Make systematic checks of guest room electrical appliances, circuits, televisions, refrigerators, and light fixtures, and repair in room deficiencies., • Inspect and maintain the hotel exterior, parking lot, and landscaping., • Maintain tools, workspaces, equipment, and grounds in clean and working order. Records, vendors, and cost control • Keep accurate and current maintenance logs, program checklists, and daily activity reports., • Monitor equipment and supply inventory and place orders through the requisition process., • Manage relationships with contractors and service providers, and coordinate bids, quotes, and contracts for third party vendors., • Assist the Operations Manager with capital requests and management of capital project contracts., • Oversee small projects and property improvement plans, and report on progress., • Keep a close watch on cost control, including labor, inventory, and subcontracted work, and recommend improvements in productivity, efficiency, and cost. Guest and team • Respond to guest and staff requests for immediate repairs., • Greet guests, visitors, and staff courteously, in rooms and in passing., • Maintain a high standard of personal appearance and proper uniform., • Ensure a safe and secure environment for guests and team members in compliance with regulatory requirements and Hotel policy. Supervisory Responsibility • Interview, select, train, schedule, coach, and support maintenance associates., • Develop the team through coaching and feedback, set performance and development goals, and recognize good work, particularly at annual reviews., • Recommend personnel actions to the Operations Manager where needed., • Ensure maintenance staff record all hours worked accurately and are never asked to work off the clock. Qualifications Required • High school diploma, GED, or equivalent relevant work experience., • Five or more years of experience in building maintenance, engineering, construction or grounds., • Working knowledge of general repair, plumbing, painting, HVAC, or electrical systems., • Any licenses or certifications required by state or local authorities for the work performed at this property., • Basic computer skills including email, Microsoft Word, and Excel. Preferred • Prior experience as a lead in a hotel or similar property., • Friendly demeanor with strong customer service and communication skills., • Ability to work efficiently under time pressure and to prioritize competing demands., • Comfortable working independently and as part of a team. Work Environment and Schedule This position is based on the property, Tuesday through Saturday, and requires availability by telephone outside regular hours for building emergencies, which may include returning to the property. The role requires flexibility to work holidays and weekends as the property requires. Work involves exposure to cleaning chemicals, mechanical equipment, and outdoor conditions. Physical Requirements The following are essential physical requirements of this position. The Hotel will consider reasonable accommodations for qualified individuals with disabilities. • Standing or walking for approximately seventy five percent of the shift., • Frequent bending, stooping, kneeling, twisting, reaching at all levels, and positioning to complete tasks., • Firm and simple grasping throughout the shift, with some tasks requiring fine manipulation such as using small tools., • Pushing and pulling for approximately forty to fifty percent of the shift., • Crouching and kneeling for approximately twenty five percent of the shift, including inspection beneath furniture, fixtures, and equipment., • Crawling up to approximately ten percent of the shift, and climbing stairs for thirty to fifty percent of the shift., • Lifting and carrying up to forty pounds regularly.

Job Description We’ve built Rowan by rethinking the ear piercing experience from the ground up—prioritizing safety, clinical expertise, and a customer experience that feels both celebratory and trusted. Every piercing is performed by licensed nurses and guided by our Rowan Clinical Piercing Standard® and paired with our hypoallergenic products, setting a clear standard that is differentiated from traditional retail models. Our goal is to create a destination where customers feel confident, cared for, and excited to participate. Rowan is seeking a Construction + Facilities Specialist to support our growing store fleet (currently 100+ locations) and Construction + Facilities team members. In this dual-function operational role, you will serve as the backbone for both our Construction Project Managers and Facility Managers. The Construction + Facilities Specialist will bridge the gap between active studio build outs, project close out, and ongoing studio maintenance. What you'll do:Construction Project Administration & Closeouts Closeout Package Management: Oversee the construction close out process to collect, review, audit, and organize all General Contractor closeout deliverables. Including executed unconditional lien waivers, AIA documents, warranties, as-built drawings, operations manuals, and attic stock records. Tenant Allowance (TA/TIA) Draws: Manage the tenant Improvement Allowance reimbursement process to Landlords. Interpret commercial lease requirements for submission and eligibility. Tracking submittals through payment receipt. Invoice & Budget Processing: Review, analyze, and track construction invoices/pay applications against project budget, following up with stakeholders as required for timely invoicing + swift project closeout. Utilities Onboarding & Transfers: Coordinate utility setups, meter sets, account activations, and billing transfers (power, gas, water, internet) for new studio buildouts and lease turnovers. Body Art & Health Compliance Coordination: Partner with the Licensing, Regulation + Leasing Administrator, Project Manager and General Contractor to evaluate physical build out requirements associated with health inspections and body art regulations. Facilities & New Studio Turnover Coordination New Studio Turnover Services: Schedule and coordinate pre-opening vendor walk-throughs and turnover scopes for newly completed builds, including post-construction deep cleaning, professional window cleaning, and initial HVAC inspections/filter changes. Invoice & Budget Processing: Review,track, and analyze Facilities invoices against contract rates + allocated budget, following up with stakeholders as required for timely invoicing. Preventative Maintenance Scheduling: Assist in evaluating and managing routine recurring services across the fleet, including HVAC maintenance contracts, fire protection, and pest control, following up with vendors as required for timely invoicing. Engage with vendor(s) to initiate new contract addendums for new studios as they open. Vendor & Contract Management: Maintain organized vendor contracts and track insurance certificates (COIs) for all trade partners. Facilities Work Order Platform: In coordination with the Senior Facilities Manager, maintain and update all data for active studios + active vendor partners. Experience we're looking for: Minimum 3+ years of experience in a similar position (Project Coordinator, Facilities Coordinator, Retail Store Operations or Commercial Real Estate Administration) Working knowledge of commercial construction processes, standard closeout documentation (lien waivers, certificates of occupancy), and landlord tenant allowance collections. Familiarity with retail facility maintenance, commercial service trades (cleaning, HVAC, plumbing), or health department/body art permitting is a strong plus. High proficiency in digital tools: Google Workspace (Sheets, Docs, Slides), Microsoft Excel, and project/work order management software. Strong organizational, tracking, and detail-oriented skills with high accuracy in handling financial paperwork, vendor invoices, and compliance records. Exceptional communication skills with the ability to interface diplomatically with general contractors, commercial landlords, field teams, and external trades. A proactive, problem-solving mindset with the agility to shift between structured construction deadlines and urgent day-to-day facilities needs. Full-Time Benefits + Perks Medical/Dental/Vision Health Plans Short and Long-term Disability Life Insurance 401k and Roth IRA Plans Paid Parental Leave Open PTO policy Employee discounts on our amazing products! About Us: Rowan is an innovative ear-piercing and hypoallergenic jewelry brand that brings safety to the forefront with our team of licensed nurses—and celebration to every guest with our joyful approach to piercings and jewelry. Our brick-and-mortar locations across the US also provide a long-overdue alternative to the standard mall piercing. At Rowan, we believe that every ear piercing is a milestone and it should be celebrated. We believe in “Piercing for All”. Check us out on CNBC's How I Made It Check us out on the TODAY Show on NBC — How 1 woman is reinventing the ear piercing experience (today.com) How Rowan Has Created a New Pathway for Nurses Important note: Rowan believes in teamwork, collaboration, and diversity. We know our team is stronger together and we commit to staying true to these values as we grow. In a remote setting, interviewing at Rowan may include phone interviews, virtual “on-site” interviews, and on-the-job mock cases. We are committed to run a thorough process for candidates with whom we identify a potential match, and we will do our best to follow-up with each and every applicant! If you’re on the fence, just give it a try! We are an equal opportunity employer and we encourage everyone to apply! Rowan is an equal opportunity employer. All applicants will be considered for employment without regard to race, religious creed (including religious dress and grooming practices), color, national origin (including language use and possession of a driver's license issued to persons unable to prove their presence in the United States is authorized under federal law), ancestry, physical disability, mental disability, medical condition, genetic information, registered domestic partner status, marital status, sex (including pregnancy), sexual orientation, gender, gender identity (including transgender identification), gender expression, age for individuals over forty years of age, military and veteran status of any person, or any other consideration made unlawful by federal, state, or local laws (“protected characteristics”). We may use artificial intelligence (AI) tools to support parts of the hiring process, such as reviewing applications, analyzing resumes, or assessing responses and identifying potential inconsistencies or verification signals in application materials based on available information. These tools assist our recruitment team but do not replace human judgment. Final hiring decisions are ultimately made by humans. If you would like more information about how your data is processed, please contact us.

Job Description WESTCHESTER, NY Job Title: • Project Manager I Who we are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. Summary/Objective: The Project Manager (PM I) will serve as a vital team member partnering with the Lead Superintendent while reporting to the Project Executive on the full scope of the project. The PM I will be responsible for Document Control & Procurement Management, Communication, Cost Management, Project Reporting Management & People Management while representing Callahan Construction Managers throughout the full project cycle. The PM I will also have complete oversight in managing the Assistant Project Manager on task completion. Essential functions: Safety • Assist the Lead Superintendent in developing and maintaining a safety culture for the project., • Perform 4 safety inspections per month, • Discuss safety at weekly team meetings Document Control and Procurement Management • Understand the Plans, Specifications & Contracts of the project, • Understand the Owner Contract, including terms, qualifications, allowances, phasing, and logistics, • Track and manage all critical material deliveries throughout the project duration (submittal management and procurement log), • Manage risk prevention on site (Subcontractors and 3rd tier Subcontractors) by ensuring subcontracts, insurances, and Exhibit Q-1s are in place prior to mobilization Communication: • Develop & maintain positive, professional relationships with the Owner, Architect, Subcontractors and Project Team, • Manage the daily activities of the project and proactively plan for upcoming needs, • Control the prompt flow of information to Owners, Consultants & Subcontractors, • Effective presentation skills for project updates, • Effective communication with subcontractor PM and Foremen to establish good working relationship, minimize conflicts and encourage bidding on other Callahan projects. Cost Management: • Project Buyout o Create detailed & complete scopes of work o Scope review of all bidders and negotiation of the best price and scope for Callahan o Complete Buyout in advance of the needs of the project schedule • Review and supervision of the job cost control system o Set up job cost budgets o Monitor and manage all field purchases o Monitor and manage labor usage o Responsible for the bottom-line project profitability • Creating and updating of monthly cost report, including accurate forecasting of cost to complete projection, • Coordinating & Leading quarterly cost meetings, • Oversee the monthly Owner & Subcontractor Requisition processes o Monitoring & Reviewing 3rd tier vendor payment compliance • Leading and executing change management processes, • Reviewing change requests against subcontract scopes of work, • Working along with the APM, promptly pricing all change requests, thoroughly vetting all Subcontractors pricing, and submitting accurate proposals to the Owner with time extensions where required, • Overseeing prompt issuance of Subcontractor change orders to keep work flowing on site, • Effectively negotiate subcontractor change orders that impact the “bottom line” Project Management & Reporting: • Creating the baseline schedule & taking an active part in monthly schedule updates that accurately reflect current procurement status, shop drawing process, project impacts and delays, and Subcontractor staffing and production. Assist with the development of break out schedules for critical or complex areas, • Planning work in advance to eliminate conflicts in plans, specifications or between trades, • Review and supervise Risk Management & Safety Program to protect Callahan against personal injury, property damage and public liability, • Plan and manage the turnover process with field staff, • Prepare and take appropriate actions in relation to union interruptions People Management: • Managing & ensuring accuracy of APM work product, • Leading team to ensure project success, • Mentoring Assistant Project Managers Required education and experience: • Bachelor’s Degree (Preferably Engineering, Construction Management or Architecture), • 5+ Years Experience, • Prior Experience in a construction setting (Construction Management) All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color religion, sex, sexual orientation, gender identity, national original or on an applicant’s status as a protected veteran or as individual with a disability.

Job Description Temporary Job Request Number: CWP - 1519 - Project Coordinator Contingent Worker Information Position Title Project Coordinator NYPA Business Unit Business Services Experience Level 1 (1-5 years) Work Location White Plains Office Anticipated Start Date Immediate Duration of Assignment 12 month(s) Project/Assignment Staff Augmentation CWP Manager Christine.Prendergast@nypa.gov Date of Posting 09/25/2026 Due Date 10/10/2026 Work Schedule Monday through Friday. 7.5-hour workday with .5-hour unpaid lunch. Paid for actual time worked; there are no paid vacation or sick days. During NYPA and Canals holidays, the business is closed, and no work is permitted. NYPA requires a hybrid schedule of a minimum of 3 days on-site, up to including fully on-site depending on department requirements. CWPO Engagement Requirements Candidates are REQUIRED to be local to the Tri-State area and in W2 tax status as an hourly paid employee of Service Provider. Fully remote positions are prohibited. Hybrid schedules are permissible with a minimum of 3 days on-site depending on assignment and can be fully on-site depending on business needs. Remote work privileges can be revoked at any time. NYPA does not provide laptops. Instead, NYPA provides desktops and dedicated workstations which candidates will remote into from their personal equipment on virtual days. If candidate does not have proper equipment, internet connection, or he/she is deemed to not work effectively from home, the hybrid privilege will be revoked. Vendors must disclose foreign national status and all Visas at the time of candidate submission. Additionally, a Benefits Waiver and Ethics Disclosure will be required of the candidate during onboarding. Submission Instructions Your email submissions must contain: The LEGAL name of candidate (no aliases, monikers, or nicknames) Job Broadcast number in your email subject header Visa work authorization, if applicable For job broadcasts outside your contractual compensation schedules, use competitive rates based on local and state compensation. NYPA CWP staff will contact you if your candidate is selected to be interviewed, which is usually via MS Teams. Please inform your candidates that an interview does not indicate acceptance of the proposed labor rates. For all questions or concerns, please contact Christine Prendergast at Christine.Prendergast@nypa.gov or Markus Caruso at Markus.Caruso@nypa.gov. Project Overview Project Coordinator will support NYPA Renewables by assisting the team with day-to-day activities, project coordination, documentation, scheduling, procurement, and cross-functional coordination. The Project Coordinator will act as a liaison between the NYPA Renewables team and key internal and external stakeholders, including Finance, Procurement, Legal, Community Affairs, Engineering, and other supporting departments, to track activities, facilitate communication, generate reports, and help keep day-to-day activities and projects moving forward. The Project Coordinator will support the daily activities of the department and projects and contribute to the successful implementation of renewable energy projects and initiatives. This position offers an opportunity for growth and learning within the organization. Job Functions & Responsibilities • Assists in project planning, coordination, documentation, and communication including day-to-day departmental activities, scheduling, tracking, and reporting., • Coordinate project and cross-functional meetings, including scheduling, preparing agendas, taking meeting notes, distributing action items, and tracking follow-up actions., • Coordinate the Scope of Work (SOW) and RFP process for the procurement of goods and services in accordance with applicable procurement policies, including tracking required inputs, responsible parties, key dates, and follow-up actions., • Create and verify purchase requisitions in SAP and communicate with various stakeholders in Operations, Procurement, Legal, and other supporting departments., • Facilitate effective communication between cross-functional team members, stakeholders, and vendors., • Maintain weekly status reports and trackers for major projects and cross-functional activities, including responsible parties, required-by dates, and outstanding actions., • Create dashboards and leverage tools to automate reporting where applicable., • Develop and maintain schedules for major project and cross-functional activities using Excel/MS Project and track progress against key dates., • Maintain and update project and business development information in CRM and other applicable tracking systems., • Support document organization and management across SharePoint, Kiteworks, and other applicable platforms. Skills • General understanding of renewable energy project development and construction lifecycle (or willingness to learn) preferred., • Experience with project management and task-tracking tools (Smartsheet, Monday.com or similar)., • Familiarity with procurement processes, contract structure, and SOW/RFP documentation., • Experience coordinating with external developers, EPC contractors, consultants, and vendors, preferred., • Proficiency in Microsoft Office Suite (Outlook, Excel, Word, PowerPoint, Teams) and ability to quickly learn MS 365 tools (SharePoint List, Power Automate) to develop concise project reports and dashboards., • Proficiency in, or ability to quickly learn MS Project, SAP ERP, CRM, and other applicable business systems., • Strong organizational, meeting coordination, risk identification, and follow-up skills., • Strong attention to details and ability to maintain accurate project records, trackers, schedules, and status reports, including document control, version tracking, and maintaining organized project repositories., • Ability to prioritize tasks, manage multiple deadlines, and keep project documentation and files well-organized., • Strong verbal and written communication and presentation skills to effectively interact with team members, stakeholders, and vendors., • Adaptability: Flexible and open to change as projects evolve, adjusting plans accordingly. Education & Certifications • Bachelor's degree required; fields such as Business, Engineering, Sustainability, Environmental Science, or similar are preferred.

Job Description POSITION SUMMARY The Senior Construction Project Manager is responsible for the overall planning, execution, financial performance, and successful completion of assigned construction projects from preconstruction through closeout. This role serves as the primary point of accountability for project outcomes — schedule, budget, quality, and safety — while managing owner, architect, subcontractor, and internal team relationships. The ideal candidate brings deep field and commercial acumen, sound judgment under pressure, and the ability to mentor project staff while directly owning project results. KEY RESPONSIBILITIES • Lead all phases of project management for one or more construction projects, including preconstruction planning, scheduling, procurement, execution, and closeout., • Own project financials, including budgets, cost forecasting, monthly cost-to-complete reporting, and profitability tracking., • Review, negotiate, and administer prime contracts and subcontracts, including scope, insurance requirements, and change order pricing., • Develop and maintain project schedules in coordination with superintendents; proactively identify and resolve schedule risks., • Prepare, review, and negotiate change orders, RFIs, submittals, and other contract administration documents., • Manage the buyout process, including scope review, subcontractor qualification, and award recommendations., • Serve as primary client-facing contact; run owner/architect/contractor (OAC) meetings and maintain strong client relationships., • Coordinate closely with site superintendents to align field execution with contractual and schedule requirements., • Ensure compliance with safety programs, quality standards, and all applicable codes, permits, and regulatory requirements., • Manage project closeout, including punch list completion, warranty documentation, and final billing/lien releases., • Mentor and provide direction to project engineers, assistant project managers, and other project team members., • Identify risks proactively and develop mitigation strategies in partnership with senior leadership. QUALIFICATIONS • Bachelor's degree in Construction Management, Civil Engineering, Architecture, or related field, or equivalent industry experience., • 8+ years of progressive construction project management experience, including experience managing projects of significant scope and complexity., • Demonstrated experience with AIA contract documents (e.g., A101, A102, A104, A201, A401 families) and standard construction contract administration., • Strong working knowledge of project cost control, GL/cost coding, and financial reporting., • Proficiency with construction management software (e.g., Procore, Bluebeam Revu, Microsoft Project) and Microsoft Office / Excel., • Excellent negotiation, written, and verbal communication skills., • OSHA 30-Hour certification preferred, or willingness to obtain within 90 days of hire., • Valid driver's license and ability to travel to job sites as required. PREFERRED QUALIFICATIONS • Experience in [ground-up commercial / renovation / institutional — tailor to APC's typical project types]., • Prior supervisory experience managing project engineers or assistant project managers. PHYSICAL REQUIREMENTS & WORK ENVIRONMENT Work is performed both in an office setting and on active construction sites. Regular site visits require the ability to walk uneven terrain, climb stairs and ladders, and wear required personal protective equipment (PPE). Occasional lifting of up to 25 lbs. may be required. COMPENSATION & BENEFITS A. Pappajohn Company offers a competitive salary commensurate with experience, along with a comprehensive benefits package including health, dental, and life insurance, retirement plan participation, paid time off, and opportunities for professional development. \nCompany Description Mid size construction management firm located in Fairfield County. Mid size construction management firm located in Fairfield County.

Job Description Job Title: Lean Manager Employment Type: Full-Time FSLA: Salary/Exempt Division: Project Services Group Department: Project Services Group Reports to: Director of Scheduling & Lean Services Supervisory Duties: Yes Salary Range: $120,000 - $140,000 The Lean Manager will encourage a culture focused on continuous improvement by supporting our clients, project teams and company in our efforts to incorporate lean tools and philosophy within their current processes. Responsibilities / Essential Functions • Engage various levels of leadership to coach, train and teach Lean concepts., • Facilitate and collaborate with internal departments and complex project teams., • Facilitate continuous improvement events with company leaders and external clients., • Challenge project teams to focus on building a culture of continuous improvement, challenging status quo., • Set up a sustainable program for Daily Stand Up Audits, ensuring all jobs are holding a value add DSU., • Train Superintendents to effectively target roadblocks from the field and communicate to teams., • Get team to routinely pull plan with trades every 10 weeks., • Participate in lookahead meetings, assist Superintendents on updating lean schedule., • Set up a formal process of planning materials coming onsite and where it should be stored., • Train workers how look for waste and what is a non-value activity.Key Skills, • Excellent verbal and written communication skills., • Excellent organizational and project management skills., • Strong initiative and problem-solving abilities., • Ability to multi-task and self-prioritize., • Motivated and driven., • Ability to work in a team environment with a primary focus on collaboration. Requirements • Bachelor’s degree in construction management, engineering, architectural or related field., • 5+ years of experience in construction operations and/or design preferred., • 2+ years of experience in group facilitation and implementing collaborative delivery (Integrated Project Delivery, Target Value Delivery, etc.)., • Ability and willingness to travel up to 60%., • Passionate about leading changes and improving company processes., • Experience, coursework, or certification in lean practices.

Job Description Woodard & Curran is an employee-owned engineering, science, and operations firm dedicated to clean water, a safe environment, healthy communities, and happy people. We foster an inclusive, collaborative culture that supports professional growth, flexibility, and meaningful work, empowering our employees to make a lasting impact on our clients, communities, and the planet. What’s in it for you: Woodard & Curran is seeking a dynamic, detail‑oriented, and client‑focused Professional Engineer to join our Water Team as a Technical Manager. In this role, you will partner with municipal clients to plan, design, and deliver a range of wastewater projects to support our Rye Brook office. Our Mid-Atlantic team comprises a dynamic group of engineers, scientists, and design professionals who emulate Woodard & Curran’s values. Woodard & Curran creates a safe and fun environment for employees to thrive and collaborate with teams locally and nationwide to deliver clean water solutions to our clients. Who are we looking for: The ideal candidate brings strong technical depth in wastewater collection systems, a proven ability to deliver complex infrastructure programs, and experience in the evaluation, planning, design, and rehabilitation of collection systems. Familiarity with a broad range of issues related to master planning, collection systems, municipal wastewater treatment, and biosolids is preferred. In collaboration with the Client Manager and Project Manager, you will help lead the delivery of multiple projects, work directly with clients and internal teams, and support marketing and proposal efforts. Location: Rye Brook, NY Offering Flexible Remote/Hybrid Work Schedule: Expectation is 2 to 3 days in the office or onsite with clients. Travel up to 20%: Clients within the Mid-Atlantic Region, generally within a two-hour radius of Westchester County To name a few, projects may include: • Collection system assessments, planning, design, and rehabilitation, • Pumping station designs and rehabilitation, • Municipal wastewater systems, including collection system infrastructure, pumping system hydraulics, and wastewater treatment processes, • Biosolids management and renewable energy development What you will be doing at Woodard & Curran:, • Managing and executing work on wastewater system design, planning, and construction projects by leading and collaborating with multi-disciplinary teams within Woodard & Curran and with subconsultants., • Determining the overall delivery approach for projects. Partner with senior leadership to develop technical approaches to larger projects., • Scheduling and tracking project budgets, milestones, and deliverables., • Utilizing Woodard & Curran’s Project Quality Assurance Program to execute all projects., • Demonstrating strong and proactive communication skills to keep the project management and technical team(s) updated as project work progresses., • Connecting and working with external suppliers and subcontractors to support project delivery., • Interacting with clients and representing the firm in a professional manner, • Visiting client sites for meetings, proposal development, or observing construction project status., • Coordinating with contractors and clients in the field during construction to ensure that projects are executed in compliance with the Contract Documents., • Interfacing with state and local regulatory agencies and permitting officials, • Conducting and coordinating QA/QC reviews on project deliverables to ensure Woodard & Curran technical excellence standards are met., • Collaborating with leadership and resource leaders on staffing projects., • Providing input on the development of Woodard & Curran design guidelines and standards., • Preparing and delivering presentations and training programs to internal and external clients and professional associations., • Supporting business development efforts under the direction of a client manager. What You Will Need to Succeed:, • 10-15 years of consulting engineering experience., • A B.S. Degree in Civil or Environmental Engineering or an M.S. Degree is preferred., • Registered Professional Engineer in New York (or ability to apply for reciprocity)., • The successful candidate will have technical management and delivery expertise in civil and environmental engineering and an in-depth understanding of the engineering concepts associated with municipal wastewater systems., • Well-versed in state and federal regulations., • Knowledgeable in state bidding laws and funding programs., • Excellent writing, communication, and presentation skills., • Demonstrated ability to conduct effective presentations to stakeholders is a plus., • Experience with proposal writing and developing project scope, budget, and schedules. The anticipated pay range is flexible, depending on factors such as the employee's primary work location, skills, experience, and education. The following examples illustrate how the pay range for the same role can vary based on different locations. This position’s anticipated pay range is provided; the final exempt salary or non-exempt hourly pay will depend on experience level and consider a percentage-based geographic differential based on where the final candidate will be working. Geographic differentials recognize and reflect the cost of labor differences between geographic markets. #LI-TB1 Woodard & Curran offers a comprehensive benefits package. For more information about our benefits & workplace policies visit Benefit & Policy Information - Woodard & Curran. E-Verify Participation: Woodard & Curran participates in E-Verify to confirm the employment eligibility of all newly hired employees. As part of this process, we provide access to the Right to Work & E-Verify postings. Equal Employment Opportunity & Accessibility: Woodard & Curran is an Equal Opportunity Employer. We are committed to non-discrimination and make employment decisions based on job-related factors. Individuals with disabilities and protected veterans are encouraged to apply. If you require a reasonable accommodation during the application process, please contact Beth Sweitzer. Equal Employment Opportunity Policy Workplace Discrimination is Illegal Posting Woodard & Curran Terms of Use Woodard & Curran Privacy Statement Text Messaging: To support an efficient hiring process, we may send brief SMS updates or reminders. You may opt out at any time by replying “STOP.” Unsolicited agency submissions without a signed agreement are not eligible for referral fees. We may use artificial intelligence (AI) tools to support parts of the hiring process, such as reviewing applications, analyzing resumes, or assessing responses and identifying potential inconsistencies or verification signals in application materials based on available information. These tools assist our recruitment team but do not replace human judgment. Final hiring decisions are ultimately made by humans. If you would like more information about how your data is processed, please contact us.

Job Description Job Summary Infinity Contracting Services, Corp. is seeking an experienced, results-driven General Contracting Estimator to join our preconstruction team. We recognize our employees are the company’s most valuable asset. Inspiration, diligence, and encouragement toward each other, coupled with purposeful work, lead to a rewarding career—and we are proud to provide a platform where experienced construction professionals can thrive and grow. Reporting to the Estimating Manager, the GC Estimator will take ownership of full-cycle estimating for public-sector construction projects. This role is responsible for leading hard-bid, negotiated, and GMP proposals from initial solicitation review through buyout handoff. You will drive profitability and project awards by producing accurate quantity take-offs, mitigating preconstruction risk, performing comprehensive subcontractor bid leveling, and leveraging strong relationships across the NYC/tri-state trade mark Key Responsibilities • Full-Cycle Estimating & Bid Management: Lead the preparation of comprehensive, accurate cost estimates from conceptual budgets through final hard bids across all CSI MasterFormat divisions. Manage multiple concurrent bids while meeting strict tender deadlines., • Drawing & Risk Analysis: Thoroughly analyze architectural, structural, and MEP drawings, specifications, and addenda to identify scope gaps, constructability challenges, and project risks. Provide value engineering (VE) alternatives to maximize competitiveness., • Subcontractor Outreach & Bid Leveling: Solicit, receive, review, and level subcontractor and supplier proposals to ensure complete scope coverage and competitive pricing. Leverage and expand an active network of reliable NYC-area sub-trades and vendors., • Site Inspections & Stakeholder Coordination: Conduct pre-bid site walkthroughs to evaluate existing conditions and logistical constraints. Attend pre-bid meetings and coordinate directly with clients, architects, engineers, and subcontractors on RFIs, scope clarifications, and addenda., • Buyout & Project Handoff: Finalize pricing on key budget line items, coordinate bid bonds, and assemble complete, organized bid files. Establish the initial buyout plan, issue letters of intent/notices to vendors, and lead the preconstruction-to-operations handoff with Project Management., • Historical Benchmarking & Systems: Maintain accurate historical cost databases from past projects to benchmark current pricing. Operate and maintain proficiency in internal estimating, take-off, and bid-management software., • Compliance: Uphold the highest standards of integrity and comply with the company’s Code of Ethics and public/private procurement regulations. Qualifications and Skills • Experience: Minimum of 5 years of direct estimating experience with a General Contractor (commercial, public works, or institutional experience in the NYC/tri-state area strongly preferred)., • Education: Bachelor’s degree in Construction Management, Civil Engineering, Architecture, or a related field preferred (or equivalent combination of field and estimating experience)., • Technical Expertise: Strong command of blueprint reading, quantity take-offs, and all 16/50 CSI MasterFormat divisions, including self-perform and MEP trades., • Software Proficiency: Hands-on experience with digital take-off and bid-management tools (e.g., Bluebeam Revu, On-Screen Takeoff, PlanSwift, BuildingConnected, Procore, and advanced Microsoft Excel)., • Core Competencies: Proven ability to manage high-pressure bid deadlines, negotiate effectively with subcontractors, and communicate clearly with owners and project teams.

Job DescriptionBenefits: • Opportunity for advancement Safety Officer (EHSO) ???? Location: NYC Area (In-Person) ???? Pay: $55.00 – $67.00 per hour (based on experience) ???? Job Type: Full-Time Position Summary We are seeking a qualified Safety Officer to support NYC Transit, Metro-North Railroad and Long Island Railroad construction projects throughout the NYC area. This role is responsible for ensuring all field activities are executed safely, efficiently, and in full compliance with contract requirements and regulatory standards. As the on-site safety authority, you will oversee daily operations, enforce safety protocols, and maintain accurate documentation to support both compliance and project performance. Key Responsibilities Field Oversight: Conduct daily site inspections to ensure contractor compliance with approved plans, safety regulations, and technical specifications • Reporting & Documentation: Prepare detailed Daily Inspection Reports (DIRs), including workforce, work performed, and quantities for payment verification • Financial Oversight: Review and maintain accurate Time & Material (T&M) records to ensure cost transparency and accountability • Project Tracking: Utilize client recording systems to monitor progress, maintain records, and support project controls • Stakeholder Coordination: Act as a liaison between project owners, contractors, utility providers, and regulatory agencies • Safety Leadership: Enforce site-specific safety requirements, environmental regulations, and EHS protocols to promote a zero-incident cultureRequired Qualifications & Certifications Education: Bachelor of Science in Safety, Environmental Health, Industrial Hygiene, or a related discipline • Experience: Minimum 10+ years of experience in railroad health and safety compliance NYC Transit/MTA/LI Railroad project experience strongly preferred • Professional Certification (Required): Must hold at least one: CSP, CIH, or CHST • Required Training & Credentials:, • OSHA 500 Outreach Trainer for Construction, • OSHA 30-Hour for Construction, • 40-Hour NYC DOB Site Safety Manager Course Completed Certificate, • Right of Way experience for MTA agencies including NYC Transit, Metro-North and Long Island Railroad, • SSPC C-3 Lead Training and the appropriate C-5, • NYSDOL Asbestos License Class D, • First Aid/CPR certifications, • 40-Hour Hazardous Waste Worker Training and up-to-date refreshers and supervisory training, • Member of the ASSP, • Undergraduate degree in Safety and Health or related discipline a plus, • Active ASP/and or CST designation a plus, • Technical Skills: Strong technical writing and reporting capabilities Solid understanding of NYC/NYC Transit/LI Railroad construction codes, safety regulations, and environmental compliance standardsWhy Join Us? • Competitive Compensation: $55–$67 per hour based on experience and certifications, • Meaningful Work: Support critical infrastructure and environmental projects across NYC, • Stability: Long-term project opportunities in a high-demand sector, • Work-Life Balance: Accruable Paid Time Off (PTO), • Professional Growth: Work within a safety-focused, compliance-driven environmentWork Environment This is a fully in-person field role requiring regular site presence across active construction environments in the NYC area. Ready to lead safety and compliance on critical NYC infrastructure projects? Apply today.

Job Description Job Summary Infinity Contracting Services Corp is actively seeking a highly motivated Assistant Project Manager with prior construction experience to join our team to a project located in the five boroughs of New York City. We recognize our employees are the company’s most valuable asset. Inspiration, diligence, and encouragement towards each other coupled with purposeful work lead to a rewarding career, and we are proud to provide a platform with which our employees can attain their goals. The Project Engineer position will assist and support project manager, superintendent, and/or foreman on assigned project(s). The position will work under direct supervision, perform routine daily activities and gather, distribute information and deliverables, and manage project management software. Responsibilities and Duties · Setup, manage and maintain project management software for each job · Organize, maintain and process contract documents and shop drawing in order to meet project budget, schedule, and requirements · Identify, issue and manage RFIs · Formulate start-up, testing and commissioning procedures · Serve as a point of contract regarding technical information associated with the project · Verify existing field conditions and report changes to affected parties · Lead internal MEP coordination process · Facilitate required inspections, testing, and commissioning · Review contract documents for completeness and consistency · Identify project scope deviations from contract documents and field observations · Monitor construction progress for quality compliance · Resolve and manage client issued non-compliance reports · Assist the project manager with buy-outs · Release equipment and materials per approved submittals · Manage and coordinate lead times and delivery dates for equipment and material · Generate submittal, RFI, equipment, etc. logs for project stakeholders Qualifications and Skills · Bachelor’s Degree in Engineering: Mechanical, Civil, Environmental, or related engineering disciplines (or equivalent experience) · Ability to work in a multi-task environment · Strong oral and written communication · Excellent time management skills · Proficient in basic engineering computations and analysis · Working knowledge of AutoCAD software · Working knowledge of Microsoft Office Suite

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Field Operations Department: Field Operations Reports to: General Superintendent Supervisory Duties: Yes Salary Range: $90,000 - $130,000 The Superintendent will provide overall administrative and technical management at the construction project site. This role will manage all on-site construction activities including, self-perform labor, subcontractors, and consultants. Other responsibilities will include the administration of the jobsite safety program, quality management, and overall schedule coordination and supervision. Responsibilities / Essential Functions • Administer project safety program to maintain a safe and healthy work environment., • Proficient in all 5 areas of focus on their project:, • Safety, Schedule, Cost, Quality, and creating Raving Fans with all external partners., • Develop and implement a site-specific safety plan for each project assigned., • Verify that all subcontractors have a valid subcontract and an acceptable insurance certificate prior to working on site., • Serve as the OSHA competent person for various tasks or assign others to serve as competent person., • Preplan all operations to produce innovative and efficient methods to avoid hazards. The Superintendent must correct all recognized hazards immediately., • Supervise construction effort to ensure project is constructed in accordance with the plans and specifications., • Thoroughly understand the contract (owner/subcontractor), owner requirements, contract plans, contract specifications, submittals and any change documents., • Provide technical assistance on the project, interpret contract drawings and submittals, and develop construction methods consistent with contract documents., • Work with the project team to set project goals and schedule milestones., • Coordinate all required labor, equipment, small tools, permanent materials, and supplies as needed for self-perform operations., • Create the Site-Specific Quality Plan (SSQP), manage all aspects of project quality efforts., • Complete onsite material verification as required for the project., • Manage project budget requirements:, • Assist the project manager in developing budgets and monthly cost to complete., • Manage T&M process, including verification of time and materials., • Track production and submit quantities weekly., • Identify changes in the field, authorize field change requests, provide all documentation required to ensure compensation for all work performed., • Assist in the Approval process for all subcontractor requisitions., • Manage the project to meet schedule requirements and milestones:, • Develop a baseline schedule with Project Services Group., • Track progress against baseline schedule and critical path dates., • Communicate schedule requirements at weekly subcontractor meetings., • Develop a short-term plan on a weekly basis that directly supports the project schedule and looks ahead a minimum of 3 weeks., • Coordinate and lead the daily stand up and weekly foreman meetings., • Ensure that the material delivery log is updated and accurate., • Interface with client representatives, A-E representatives, other contractors, and various building officials in a professional manner., • Participate in business development. Create Raving Fans on current projects. Utilize contacts to initiate leads for future projects., • Participate in quarterly superintendent and safety meetings, as well as periodic training sessions., • Supervise assigned foremen, assistant superintendents, and project engineers.Key Skills, • Strong communication skills., • Strong initiative and problem-solving abilities., • Ability to multi-task and self-prioritize., • Motivated and driven., • Ability to work in a team environment with a primary focus on collaboration., • Ability to work with and manage multiple people. Required Experience • Bachelor’s degree in construction management with at least 5 years of experience in the construction field or any related field., • Understands building plans and specs., • CSL preferred., • OSHA 10 Certification required; OSHA 30 Certification preferred., • Thorough knowledge of Corporate/Industry Safety standards., • Working knowledge of CPM schedule., • Working knowledge of cost report and labor production report., • Thorough knowledge of corporate quality program., • Thorough knowledge of subcontract language., • Basic computer knowledge.

Job Description Summary/Objective: The Lead Superintendent oversees the full scope of the physical construction of the project. The Lead Superintendent is responsible for Safety, QA/QC, Subcontractor Management, Document Control, Schedule, Relationship Management & Project Management while representing Callahan Construction Managers throughout the full project cycle. The Project Superintendent is responsible for the supervision of the day-to-day work in the field and is expected to turn out high-quality work in the largest possible quantities for the lowest possible cost in the shortest possible time. The Lead Superintendent also plans in advance and ensures the flow of personnel and materials will be available. All Callahan employees are required to be respectful and professional in their day-to-day work and to be ethical in all practices. Essential Functions Safety: • Enforce compliance with all safety laws and regulations. Stop unsafe work and order Callahan, Inc., and Subcontractor employees away from hazards, etc. Ensure follow through of all safety recommendations of the Safety Manager, • Manage safety inspection reports, verify remediation has occurred and document, • Manage implementation and updating of NFPA 241 Plan. Notify and send all updates to Fire Department, • Manage site security daily - gates, fence line, signage, cameras, • Walk entire project daily reviewing overall compliance and document in the daily report, • Ensure that the project is prepared for OSHA inspections and take lead in any visits or inspection processes, • Notify Safety Manager of all incidents and near misses, • Hold stand downs as needed, • Coordinate with subcontractors and the Safety Manager for all JHAs and SOAP plans in advance of the work. QA/QC: • Create QA/QC management plan with Project Team, QAQC Manager and In House Architect, • Lead the project QA/QC process, ensuring all team members are participating in documentation, communication and execution of the plan, • Drive the process for all mockups and quality benchmarks, • Schedule, lead and document all area-specific preconstruction and mockup meetings, • Continuously monitor job progress on-site, checking all work to ensure compliance with Contract Documents, • Update QA/QC Manager on schedule, progress and issues, • Oversee the punch process, deficiency log, work to complete lists and final acceptance, utilizing PlanGrid, • Manage and verify MAAB, ADA, & FHA Compliance Subcontractor Management: • Ensure work is available to subcontractors to be successful, • Identify and resolve problems and conflicts, organize meetings and cooperate with team members in various roles as necessary, • Maintain good communication and relationships with the labor force and their leaders, • Initiate all Subcontractor Pre-mobilization Meetings (Exhibit S) with the subcontractor and all required parties to ensure that all requirements are understood, • Manage risk prevention requirements of site and Subcontractors by ensuring subcontracts and insurances are in place prior to mobilization, • Initiate badge program and ensure that all Subcontractor employees have undergone badge process and safety review prior to starting work, • Execute weekly subcontractor meetings, • Understand all subcontract scopes of work, identify scope gaps and oversee subcontractors to ensure compliance, • Manage and enforce daily cleanup and housekeeping; send notice to non-participating subcontractors, • Organize all logistics, delivery management and documentation of materials with project field staff, • Notify the Subcontractor and PM/APM of any delays resulting from labor, equipment or material shortages, • Give notice as required by subcontract agreement with written confirmation to a Subcontractor prior to performing any work for which a back charge will be processed Document Control: • Understand the plans, specifications, site, estimate, owner contract and qualifications, and subcontracts to the extent that the scope, magnitude, and relationship to the finished product are known Understand budget and attend all job cost meetings, • Manage Daily Reports, • Prepare and complete the Project Daily Report containing an accurate record of trade forces and activities, areas worked, deliveries, visitors, weather and any other pertinent information using Viewpoint Team, • Manage T&M Log - verify all slips for work was approved, log is fully detailed, • Manage and perform shop drawing review, • Provide daily photo documentation of project and upload to job folder, • Compile and maintain all permits, testing and inspections required for successful project completion and acceptance related to assigned area or scopes, • Create and track hot lists Schedule: • Create, manage and update the construction baseline schedule, • Create and update 3 week look ahead weekly, within the parameters of the current project schedule, • Provide input for schedule update, • Create and manage break out schedules for all areas, • Plan work in advance of actual operations to permit time for eliminating conflicts in plans, specifications or between trades and to ensure material and equipment deliveries as required, • Coordinate and oversee the scheduling of subcontractors, consultants, inspectors, and vendors., • Monitor and communicate with subcontractors to ensure that they maintain adequate forces and productivity to execute the work in accordance with the schedule requirements., • Own, track, update and notify of all schedule delays to Lead Superintendent, PM and PX Relationship Management: • Establish and maintain positive relations with Subcontractors, Owner, Architect, and Engineers, • Foster and encourage team environment, • Meet abutters, providing a brief overview of the project and providing your contact information, • Communicate effectively in a prompt and professional manner, • Schedule and walk with all non-MEP inspectors - Building Inspector, FD, Conservation, etc. Project Management: • Develop project specific, site-regulations, • Develop detailed phasing and turnover plan, • Prepare the site for union interruptions and understand actions in case of same, notify per procedure, • Manage daily activities to plan in advance for all needs of project, • Understand the plans, specifications, site, estimate and contract to the extent that the scope, magnitude and relationship to the finished product are known, • Attend weekly OAC meetings, • Provide input for and track procurement log, • Understand and track budget, • Notify the Project Manager of all required cost changes involving field conditions and receiving authorization before proceeding, • Manage all tool and equipment needs directly through NESB, • Follow the BIM Execution Plan and participate as required, • Create schedule for and provide weekend coverage of Project in conjunction with entire team Leadership • Provide clear direction and consistent feedback to your team, • Motivate and coach your team to achieve goals, • Mentor your staff and build relationships, • Delegate tasks to challenge your team and provide growth opportunities, • Engage and promote training and continuous learning for yourself and your team Development Goals Job Title: • Lead Superintendent Summary/Objective: The Lead Superintendent should be exhibiting the behaviors below when they are ready to be promoted to General Superintendent. The managers will use these goals to make personalized goals with their direct reports to help them achieve a promotion to the next position. Safety: • Finds new ways to promote safety planning with JHAs for their subcontractors, • Runs a safe job site with high inspection report numbers and can provide mentoring to other Project Superintendents QA/QC: • Minimizes punch list work on their projects with thorough QAQC throughout construction, • Utilizes the QAQC process to minimize items that get to the deficiency log by bringing 3rd parties into the process and closely monitoring the work., • Utilizes lessons learned from other projects to apply to their project through area preconstruction or mockup meetings. Supplies lessons learned to other teams in similar conditions., • Understands big picture of market volatility and strategizes for material and equipment management Subcontractor Management: • Plans for work with subcontractors and other projects throughout the company to ensure appropriate manpower is planned, • Identifies all relevant and appropriate content is included in Exhibit S. The ability to modify the meeting agenda as needed for a trade., • Coordinates with Project team ahead of mobilization to assure all compliance items are in place. Proactive in discussions with subcontractors to hit the ground running seamlessly, • Manages daily cleanup and housekeeping as a requirement for all, no exceptions, with worker safety as a priority Document Control: • Understands the big picture for daily reporting and how it relates to owner delays and insurance claims, • Sets a precedent with the entire subcontractor team regarding T&M work and holds true to that throughout construction. Utilizes relationship give and take to minimize costs., • Proactively brings an issue or RFI up to the General Superintendent if it is potentially impactful to other projects. Invested in current project impacts and the betterment of the company on future jobs as those relate to project issues., • Ensures the full submittal process is completed in coordination with procurement requirements Schedule: • Leads their team and site utilizing the three week look ahead schedule, • Can review a schedule for completeness and appropriate durations and logic; understands critical path., • Manages the owner delay process with the PX and communicates with other Superintendent regarding subcontractor delays that could impact other projects Relationship Management: • Leverages subcontractor, owner and design team relationships to assist with other Callahan projects., • Creates and builds strong teams., • Effective and motivational written and verbal communication with all levels Project Management: • Has experience in multiple building types, • Identifies issues in scopes/contracts/ Quals for completeness or scopes gaps prior to executed contract or work in place, • Create solutions for potential procurement issues by resequencing and problem solving, • Helps establish budgets and understands owner contract terms to facilitate ways to improve profitability Leadership: • Mentor to many and responsible for assessing, creating & delivering training

Job Description Gunner Roofing is soaring ahead as the fastest-growing roofing company, known for exceptional craftsmanship, stellar customer service, and innovative technology. We’ve patented a unique website that makes us the first and only company in the nation to provide accurate roof quotes completely online, in just minutes. Winner of multiple awards including GAF’s Cutting Edge Contractor Award 2023 & DaVinci Masterpiece Contractor Project of the Year 2023 along with Fast Company’s Most Innovative Companies 2024, & Inc. Best Workplaces 2025. Our people are the backbone of Gunner, each member bringing unique skills and passion to the table, driving us forward and upholding our commitment to education, communication, unmatched speed, innovation, and craftsmanship. Our people are aided by an experience that enables customers to easily purchase roofing online. This blend of traditional craftsmanship and digital ease underscores our dedication to an exceptional customer experience. What part will you play? • As a Roofing Project Manager at Gunner, you’ll be the driving force behind every remodeling project once it’s sold. You’ll oversee all aspects of execution, ensuring contracts are delivered flawlessly, on time, and to the highest standard. Acting as the on-site leader, you’ll manage subcontractors, safeguard quality, ensure safety compliance, and deliver a remarkable customer experience from start to finish — with minimal supervision and maximum impact. You own the homeowner relationship from the first walkthrough to the final handshake. You are the person they call, and the reason they refer us to a neighbor. What will you do? • Serve as the on-site expert, leader, and primary communicator for assigned projects., • Coordinate with dispatch, procurement, and customer success teams to keep projects running smoothly., • Supervise and lead subcontractors and crews — ensuring safety, teamwork, discipline, and high-quality workmanship., • Review and understand the project scope and specifications before work begins., • Track and verify material and equipment deliveries, reporting discrepancies to procurement., • Advise customers on potential scope changes and process change orders directly., • Ensure OSHA compliance and adherence to all applicable regulations., • Monitor and inspect installation quality throughout each project., • Communicate proactively and effectively with both customers and internal teams at every stage., • Own escalations personally. When something goes wrong on a job, you are the one who calls the homeowner first, explains it plainly, and makes it right., • Use technical knowledge, attention to detail, and customer service skills to start, run, and close projects on time., • Perform other duties as assigned. Compensation • Base Salary: $90,000 - $120,000, • Two-week onboarding program, • American Express for business expenses, • Company Gas Card, • Company Vehicle, including insurance and fuel coverage Requirements • 2+ years in construction project management or site supervision with direct customer interaction., • Hands-on experience in residential construction; experience with roofing, siding, and/or window and door installation is ideal., • Proven ability to deliver 5-star experiences to clients., • A track record of being the person a homeowner calls: de-escalating problems, recovering a job that went sideways, and turning a frustrated customer into a referral., • Strong skills in guiding teams, enforcing standards, and managing performance., • Excellent written, verbal, and interpersonal skills., • Familiarity with Google Workspace and DocuSign., • Ability to manage schedules using a digital calendar., • Understanding of contracts, subcontracts, and terms & conditions., • Self-motivated, disciplined, resourceful, and comfortable working with ambiguity., • Professional demeanor and presentation., • OSHA certifications., • Valid driver’s license with an acceptable driving record, and demonstrated adherence to company safety standards., • Willingness to learn and grow with the company., • Ready to walk us through one specific job that went wrong and exactly what you said to the homeowner. We will ask, and it is the part of the interview that matters most. Benefits • 401(k): Company match after 6 months, • United Healthcare (medical, dental, vision) with company contribution after 60 days, • PTO: Unlimited plan after 60 days