Trabajos construction safety manager en New Rochelle, New YorkCrear alertas

Securitas Technology, part of Securitas, is a world-leading provider of integrated security solutions that protect, connect, and optimize businesses of all types and sizes. More than 13,000 colleagues in 40 countries are focused daily on our purpose to help make your world a safer place and our commitment to deliver an unparalleled client experience. With clients at the heart of all we do, our people, knowledge, and technology power our connected ecosystem of health, safety and security solutions and services. ORGANIZATIONAL RELATIONSHIPS Closely work with together with the BIM Manager and system’s design engineers to provide 3D design aid throughout the project’s life cycle. Reports to Enterprise Systems engineering manager. SCOPE OF RESPONSIBILITY The Engineer is responsible for working closely with the BIM Manager and Systems Engineer to create a 3D model of the integrated security systems design submittal for approval by the customer or representative and in accordance with project specifications, drawings, codes, and regulations, manage and create the design submittal (drawings, bill of material, calculations, as-builts, etc.) and maintain the submittal during changes to the contract. Work within Security Technology systems group on the design and integration of security systems, access control, intrusion detection systems, communication, CCTV, Intercom systems, computer, and networking. Develop detailed design schematic and review 2D and 3D drawings for electronic and electrical products. This position will require working closely with project managers, design engineers, engineering specialists, manufactures, customers, engineering firms and other external experts. This position will require working in the Elmsford-NY office or the Fair Lawn-NJ office. Travel if might needed is less than 10% of the time. There is no relocation package available for this position. Job Requirements: ESSENTIAL FUNCTIONS • Basic working knowledge of Electronic Security Systems and features., • Creating Detailed 3D Models utilizing Revit, AutoCAD, and Navisworks to develop detailed 3D models of architectural designs., • Work closely with Design Engineers, architects, and other team members., • Updating and Modifying Models. As plans and specifications change, update and modify existing models accordingly., • Generating 2D Drawings and Details. Extract 2D drawings and construction details from 3D models., • Clash Detection and Coordination. Run clash detection analyses to identify conflicts or discrepancies between different building elements., • Attend Regular Project clash detection meetings and be prepared with clash reports to facilitate coordination meetings among project stakeholders., • Adherence to BIM Standards. Ensure that all models comply with project-specific BIM standards and protocols., • Maintaining BIM Libraries. Create and update BIM families within the project’s library., • Contributing to BIM Standards Development and actively participate in enhancing BIM standards and best practices within the organization., • Ability to handle multiple projects, schedule work and communicate effectively to peers. ADDITIONAL RESPONSIBILITIES • Be prompt, reliable, and on time in all aspects of your engagement while maintaining a high level of attention to detail and accuracy., • Perform any additional duties as required or assigned. SPECIAL KNOWLEDGE, SKILLS, AND ABILITIES • Security engineering experience is preferred but not a must., • BS in EE Engineering or equivalent is required., • Computer skills to include Revit, AutoCAD, Navisworks and MS Office., • Knowledge of ISO 19650 standards, • AC and DC circuitry, voltage drop calculations and wire sizing., • Basic knowledge of network and system security principles, not only in theory., • Executing enterprise engineering techniques., • Proven experience managing workload and pressure situations. Securitas offers comprehensive benefits including: • Company training and industry leading certification program, • Opportunity for annual merit pay increases, • Medical, Dental, Vision, and Life Insurance, • Company Paid Short Term and Long-Term Disability, • 401K with 60% Match up to 6% of salary, • Paid vacation, holiday, and sick time, • Educational Assistance, • Exceptional growth opportunities, • Wide variety of employee discounts on travel, equipment, and more! We are a nationwide provider of security solutions and an equal opportunity employer committed to a diverse workforce. Our core values of Integrity, Vigilance and Helpfulness are proudly demonstrated daily by our employees to our customers and the communities we service.

Simone Development is a full-service, privately held commercial and residential real estate investment and development company with a distinguished resume and reputation established over five decades. As a full service developer, we have the ability to rapidly move any project from site selection, acquisition, financing, construction, leasing, property management and maintenance. The core principles that define the Simone organization are the stability, creativity and professional expertise of our management team; an aggressive long-term business plan; a commitment to excellence and tenant service; our close relationships with strategic partners, tenants, lenders, municipalities, and real estate professionals; a consistent ability to add value; and most importantly, our unwavering pursuit of visionary development. Position Summary The Property Manager creates tenant satisfaction and retention by facilitating the initial installation of the tenant, fostering two-way communication channels, implementing clearly understood life safety programs, and responding to tenant requests in a timely and effective manner. The Property Manager maximizes portfolio value by maintaining the properties, budgeting and managing operational expenses, and by identifying and implementing capital improvements that will increase the efficiency and value of the properties. In so doing, the Property Manager operates in alignment with the vision, mission and strategy of Simone Development team in a manner consistent with our core values. Job Responsibilities • Assure that the property is maintained and operated at a level that 1) causes tenants to be highly satisfied and inclined to want to continue as tenants beyond lease expiration, 2) causes potential tenants to be positively impressed, and 3) adds to the good reputation of the property and its owners., • Respond to the demands of tenants in a timely and responsive manner, and handle “non-legitimate” demands in an effective manner., • Maintain professional, working relationship with all tenants at assigned properties., • Determine whether the responsibility for repair/maintenance is the responsibility of the Landlord or the Tenant, and communicate to the Tenant when repair/maintenance is not the Landlord’s responsibility. When work is performed, work with the PM team to follow up with tenant to be sure the complaint is resolved., • Rapidly respond to emergency situations and coordinate solutions with the team., • Oversee Construction department in coordinating tenant build-outs, reconfigurations and expansions, etc., at assigned properties., • Review vendor contracts with SVP Property Management, and oversee and maximize the service delivery, output, and effectiveness of all vendors and contractors., • Bid, negotiate and implement service contracts with all 3rd party vendors in accordance with company policy., • Ensure properties are compliant with all building and fire codes., • Assist in showing space to brokers and potential tenants, initiate lease discussions when appropriate, and assist with determining floor layouts and work letters, as needed., • Work with the VP Leasing, as needed, on lease renewals., • Maintain a full knowledge of and be responsible for all activities at assigned properties., • Approve bill-backs, CAM, etc., and make sure they are collected in a timely manner., • Review and approve Purchase Orders and invoices related to the properties., • Assist with rent collection and other tenant receivables., • Prepare information needed for landlord/tenant court and appear in court as owner’s representative., • Prepare the annual operating and capital budgets and monthly variance reporting for assigned properties., • Monitor year-to-date actual vs. budget to assure that the property is running within budget., • Document any significant variances in writing and be prepared to discuss them at the budget review., • Review CAM reconciliations and resolve discrepancies with Property Accountants before invoices are sent to tenants., • Explain CAM charges and RE taxes when challenged by tenants, with assistance from Property Accountants when needed., • Communicate orally, and coordinate registered letter process, with any tenant who is violating lease terms (e.g., parking in wrong spaces, leaving garbage in wrong place, etc.) – or who is otherwise causing use-of-space or care-of-space problems., • Assure all utility meters are being read and billed as actual (not estimated), and work with the Property Management team at least five days prior to Tenant vacating to make sure utility accounts are switched over to owner’s name to avoid lapse in services (gas, electric, water, etc.). Assure that a master list of meter numbers is maintained correctly., • Resolve issues related to any meters/addresses that are not being billed correctly., • Work with Assistant Property Management to report all damage, injuries or potential claims to the legal department immediately with a detailed incident report containing all pertinent facts, names, dates, times, locations, etc., • Assure that “move out” and “move in” processes are completed in a timely manner and that properties are in optimum condition for leasing., • Value engineering of alternative methods of repair and/or replacement of equipment., • Visit properties frequently and report work order requests through the work order management system., • Work with the Property Compliance Manager to assure that the tenant always maintains proper insurance., • Work with Property Compliance Manager and liaison with Building Departments to coordinate activities needed to obtain Certificates of Occupancy (TCOs & Cos), clear violations, obtain permits, comply with code requirements, etc., • This job description is not designed to cover or contain a comprehensive listing of activities, duties or responsibilities that are required in this role., • Duties, responsibilities and activities may change or new ones may be assigned at any time with or without notice., • Other tasks/assignments/research as needed. REQUIREMENTS: • Bachelors degree preferred, • 5+ years of Building Operations/Management experience in a New York City Class A Office Buildings, • Working knowledge and experience with Payscan, Yardi, Construction Manager and Facility Manager preferred, • Excellent MS Excel skills, • Comprehensive knowledge of NYC local building codes, • Must have understanding of accounting procedures and financial reports It is the policy of Simone Development (SIMDEV) to provide equal employment opportunities to all qualified individuals without regard to race, color, creed, religion, national origin, ancestry, age, gender, pregnancy, sexual orientation, gender identity or expression (including transgender status), age, marital status, familial status, citizenship status, disability or genetic information or handicap or status as a Vietnam-era or special disabled veteran in accordance with all applicable federal, state and local laws. Recruiters need not reach out. The organization is sourcing candidates directly at this time.

Project Engineer I (w-2 candidates can apply) Location: White Plains, NY Work Schedule: Monday–Friday, 7.5 working hours per day Job Overview We are looking for a Project Engineer to manage energy-efficiency projects that help customers reduce energy consumption and operating costs across New York State. Key Responsibilities • Manage multiple energy-efficiency projects involving HVAC, lighting, electrical systems, building controls, and building upgrades., • Prepare engineering calculations, cost estimates, feasibility reports, and energy savings analyses., • Coordinate with customers, contractors, consultants, and equipment vendors., • Review engineering designs, specifications, contractor bids, budgets, and project schedules., • Monitor project progress, construction quality, safety, and code compliance., • Review invoices, change orders, and project financial documentation. Required Qualifications • Bachelor's degree in Mechanical Engineering, Electrical Engineering, or a related field., • Minimum 5 years of engineering experience., • Project management experience., • Strong knowledge of building mechanical/electrical systems and applicable codes., • Experience coordinating contractors, consultants, and multiple projects., • Good communication, analytical, and problem-solving skills. Preferred Qualifications • Professional Engineer (PE) license., • PMP or Certified Energy Manager (CEM) certification., • Working knowledge of SAP, Oracle Primavera, and Microsoft Teams., • Experience in energy efficiency, energy audits, or building retrofit projects. Additional Requirements • Must be able to work onsite at least 3 days per week., • Travel to customer sites in NYC boroughs may be required., • Occasional work outside normal business hours may be needed.

Ready to help lead the growth of a thriving water and wastewater practice in New York? Creighton Manning Engineering and Surveying, a GAI Company, is seeking a talented Project Manager with 10+ years of water/wastewater experience to join our dynamic team. This is more than a project management role, it's an opportunity to help build a growing business, strengthen client partnerships, and deliver critical infrastructure projects that make a real difference in communities across New York. Working from any of our offices in Albany, Poughkeepsie, Syracuse, or White Plains, you'll lead projects spanning planning, design, permitting, and construction while collaborating with GAI's experienced water professionals. You'll have the opportunity to expand relationships within the municipal water and wastewater market, pursue new opportunities, and play an integral role in the continued growth of our practice. If you're energized by the opportunity to blend technical excellence, client leadership, and business development while helping shape the future of a growing division, we'd love to hear from you. Plus, the successful candidate will be eligible for a generous SIGN-ON BONUS. Job Duties • Independently perform and guide multi-discipline teams on the completion of water and wastewater planning, evaluation, design, and construction projects related to collection, conveyance, and distribution systems, pump stations, storage and treatment facilities, and asset upgrade/rehabilitation., • Plan and manage projects from inception through construction and start-up, including client coordination, team chartering, scope, schedule and budget development and management, safety, quality assurance/quality control, project profitability, and staff workload coordination., • Provide technical execution and oversight of design projects including schematic/preliminary design, design development, final design, specifications, permitting, construction contract document production, bid-phase services, and construction-phase services., • Lead water/ wastewater consulting tasks, including flow projections, hydraulic modeling, master planning, detailed design calculations, alternative analysis and selection, cost estimating, equipment selection, and project prioritization., • Hire, mentor and develop junior staff for both technical and project management knowledge, skills, and abilities., • Contribute to business development activities, including opportunity identification, proposal development, interviews/presentations, and client relationship cultivation., • Serve as a primary doer/seller for the New York Water Division, growing into a “go-to” Creighton Manning representative to clients, key contractors and design partners, professional organizations, and in the communities we serve. Required Minimum Qualifications: • Minimum 10 years of experience in the municipal water/ wastewater market involving master planning, hydraulic modeling, technical reports, design of distribution and conveyance systems (including pipelines in public rights-of-way), treatment process/facility design, regulatory permitting, services during construction, and/or other technical services., • Minimum 2 years of experience serving as a Project Manager leading and directing multi-discipline project teams, both internally and externally, with a track record of delivering on time and on budget while meeting or exceeding client expectations., • Excellent technical writing, verbal communication, and leadership skills working in a dynamic team environment., • Sense of urgency and self-initiative to meet deadlines and develop new business opportunities., • Experience in Microsoft Office, Microsoft Project, AutoCAD/ Civil 3D, ArcGIS, and industry hydraulic and design modeling software., • Integrates solutions to complex problems across specialty areas., • Demonstrates leadership Preferred • 10+ years of engineering experience, with at least 3 of those years serving in an engineer-of-record capacity for water and/or wastewater projects., • Experience with the delivery of cross-market projects., • Trenchless pipeline design, permitting, and construction experience., • Facility and pipeline condition assessment field and data management experience., • Successful client management/ business development experience in Upstate New York. Pay Range Albany/Syracuse – $55/hour – $68/hour Poughkeepsie - $59/hour - $73/hour Westchester- White Plains – $63/hour – $78/hour Why Creighton Manning At Creighton Manning, exceptional people have an exceptional place to work, grow, lead, and achieve. Explore an array of opportunities in locations across the U.S. and join accomplished colleagues in tackling challenging projects for a range of markets. Enjoy comprehensive benefits and feel good about being part of a collaborative team that’s committed to supporting the communities we serve. Join Creighton Manning and distinguish yourself in a company poised for unlimited growth. Creighton Manning is committed to diversity, equity, and inclusion by fostering a workforce that represents different communities, cultures, and viewpoints. We will continue to build mutual trust and respect where employees are empowered to share their diverse perspectives, experiences, and ideas. Benefits To Working At Creighton Manning Include • Competitive salary - Creighton Manning is committed to paying market-based salaries, • Comprehensive benefits package including medical, vision, dental, company paid Long Term Disability and Short-Term Disability (benefits start within 30 days of hire), • New paid Maternity/Paternity/Adoption program, • Generous Paid Time Off and 7 paid holidays, • 401k company match, • Tuition Reimbursement

Job Description Beware of Recruitment Fraud: We are committed to protecting job seekers from recruitment fraud. Please be aware that all official communication regarding opportunities with our firm will come exclusively from an email address ending in @RoseNYC.com. We will never request payment, financial information, or sensitive personal documentation during the application process, and we will never extend a job offer without first conducting a formal in-person interview. If you receive a message that appears suspicious or does not originate from this domain, please mark it as spam or phishing and report it to us directly at recruiting@rosenyc.com. Overview Rose Associates is a recognized market leader in multifamily and mixed-use real estate. Based in New York City, we own, develop and operate leading properties in urban markets from Philadelphia to Boston and across all residential asset classes, including market, regulated, workforce and affordable housing. Our dynamic services platform spans development, construction, property and asset management, leasing, marketing and accounting/financial operations. We partner with private owners and institutional investors globally to develop and operate some of the most iconic assets in our markets. We rely on technology and the deep expertise of our team to consistently outperform the market in the operation of more than 30,000 units across some 250 properties in the most challenging housing markets in the country. For the past three years, Rose has been the top-rated manager for resident satisfaction in the United States on the Kingsley Surveys platform (peer group of firms with 10-30,000 units being surveyed). Established in 1925, Rose Associates possesses a century of real estate expertise and an impeccable reputation for excellence and integrity. Today a woman-owned business led by CEO Amy Rose, we are committed to a corporate culture of belonging and inclusion that is widely admired in the industry. As we expand across the Northeast, Rose is providing opportunity for our team members to grow their careers in an environment of respect and support. Join us on the forefront of innovation and growth – Rose Associates is where excitement meets opportunity! We are seeking a highly motivated and customer-focused Residential Property Handyperson to join our vibrant team and contribute to the overall maintenance, satisfaction and well-being of our residents. The ideal candidate will be proficient in a variety of repair and maintenance tasks, contributing to the overall well-being of the property and ensuring a safe and comfortable environment for residents. Essential Functions • Perform routine maintenance and repairs on residential units, including plumbing, electrical, HVAC, appliance repair, and carpentry tasks., • Address minor HVAC issues, Inspect, troubleshoot, and repair household appliances to ensure functionality and safety and collaborate with specialized technicians for major repairs. Coordinate with vendors for appliance replacements when necessary., • Paint and complete drywall repairs to maintain a fresh and appealing appearance throughout the property., • Repair and replace flooring materials as needed, ensuring a safe and aesthetically pleasing environment., • Perform routine maintenance on units in preparation of apartment turns, and maintain maintenance shop, including related inventory of supplies., • Conduct regular safety inspections, identifying and addressing potential hazards promptly., • Be available for on-call duties and respond to emergency maintenance requests outside regular working hours., • Comply with workplace safety and OSHA regulations., • Must be present on-site and be able to move throughout the building to address building related matters and meet with tenants, staff, vendors and visitors., • Ability to ascend and descend stairs, as well as positioning oneself in small spaces for building inspections and maintenance repairs and lifting and moving large or heavy objects in excess of 50 pounds., • Must be comfortable with exposure to varying environmental climates and circumstances. Qualifications • High School diploma or equivalent and / or previous experience in a handyman capacity is preferred., • Knowledge of safety protocols, building codes and utilization of related machinery and tools is required., • Strong problem-solving skills and attention to detail., • Currently possesses EPA 608 Universal technical certification, S12, S13, S95, P99 or capable of obtaining the required certifications., • Proficient in computer operations, particularly skilled in using Microsoft Office and Yardi software., • Work authorization (required)Hourly pay range - $24 - $27 Powered by JazzHR 4YTGbI0GuX

Job Description Beware of Recruitment Fraud: We are committed to protecting job seekers from recruitment fraud. Please be aware that all official communication regarding opportunities with our firm will come exclusively from an email address ending in @RoseNYC.com. We will never request payment, financial information, or sensitive personal documentation during the application process, and we will never extend a job offer without first conducting a formal in-person interview. If you receive a message that appears suspicious or does not originate from this domain, please mark it as spam or phishing and report it to us directly at recruiting@rosenyc.com. Overview Rose Associates is a recognized market leader in multifamily and mixed-use real estate. Based in New York City, we own, develop and operate leading properties in urban markets from Philadelphia to Boston and across all residential asset classes, including market, regulated, workforce and affordable housing. Our dynamic services platform spans development, construction, property and asset management, leasing, marketing and accounting/financial operations. We partner with private owners and institutional investors globally to develop and operate some of the most iconic assets in our markets. We rely on technology and the deep expertise of our team to consistently outperform the market in the operation of more than 30,000 units across some 250 properties in the most challenging housing markets in the country. For the past three years, Rose has been the top-rated manager for resident satisfaction in the United States on the Kingsley Surveys platform (peer group of firms with 10-30,000 units being surveyed). Established in 1925, Rose Associates possesses a century of real estate expertise and an impeccable reputation for excellence and integrity. Today a woman-owned business led by CEO Amy Rose, we are committed to a corporate culture of belonging and inclusion that is widely admired in the industry. As we expand across the Northeast, Rose is providing opportunity for our team members to grow their careers in an environment of respect and support. Join us on the forefront of innovation and growth – Rose Associates is where excitement meets opportunity! We are seeking a highly motivated and customer-focused Residential Property Handyperson to join our vibrant team and contribute to the overall maintenance, satisfaction and well-being of our residents. The ideal candidate will be proficient in a variety of repair and maintenance tasks, contributing to the overall well-being of the property and ensuring a safe and comfortable environment for residents. Essential Functions • Perform routine maintenance and repairs on residential units, including plumbing, electrical, HVAC, appliance repair, and carpentry tasks., • Address minor HVAC issues, Inspect, troubleshoot, and repair household appliances to ensure functionality and safety and collaborate with specialized technicians for major repairs. Coordinate with vendors for appliance replacements when necessary., • Paint and complete drywall repairs to maintain a fresh and appealing appearance throughout the property., • Repair and replace flooring materials as needed, ensuring a safe and aesthetically pleasing environment., • Perform routine maintenance on units in preparation of apartment turns, and maintain maintenance shop, including related inventory of supplies., • Conduct regular safety inspections, identifying and addressing potential hazards promptly., • Be available for on-call duties and respond to emergency maintenance requests outside regular working hours., • Comply with workplace safety and OSHA regulations., • Must be present on-site and be able to move throughout the building to address building related matters and meet with tenants, staff, vendors and visitors., • Ability to ascend and descend stairs, as well as positioning oneself in small spaces for building inspections and maintenance repairs and lifting and moving large or heavy objects in excess of 50 pounds., • Must be comfortable with exposure to varying environmental climates and circumstances. Qualifications • High School diploma or equivalent and / or previous experience in a handyman capacity is preferred., • Knowledge of safety protocols, building codes and utilization of related machinery and tools is required., • Strong problem-solving skills and attention to detail., • Currently possesses EPA 608 Universal technical certification, S12, S13, S95, P99 or capable of obtaining the required certifications., • Proficient in computer operations, particularly skilled in using Microsoft Office and Yardi software., • Work authorization (required)Hourly pay range - $25 - $28 Powered by JazzHR QK1qxZaybO

Dual Fuel Company LLC is a full-service Mechanical, Electrical, and Plumbing (MEP) contractor headquartered in Mount Vernon, NY, serving New York City's multifamily, commercial, and institutional markets. With over 100 employees and a reputation built on technical excellence and accountability, Dual Fuel designs, installs, maintains, and monitors HVAC and plumbing systems that deliver maximum comfort at the lowest possible lifecycle costs. Our team is guided by a set of core values: we want to see our colleagues develop and thrive, our customers' problems are our problems, every interaction matters, we are data driven, we leave no stone unturned, and we can master anything. Position Overview The Project Manager is the executive owner of every project they carry — accountable for schedule, financial performance, client relationship, contract compliance, subcontractor performance, and closeout from contract award through final billing. The PM leads a project team composed of an Assistant Project Manager, a Site Superintendent, and one or more Foremen, and is the single point of escalation for all project-level decisions. This is an office-based role with regular site visits. The PM must be equally fluent in construction documents, financial reporting, and client communication. Key Responsibilities Client & GC Relationship • Serve as the primary external point of contact for all client and GC communications on assigned projects., • Provide proactive project updates and ensure the client is never surprised by schedule, cost, or scope developments. The APM supports meeting documentation and tracking; the PM owns the relationship and the substance of all communications., • Attend all required project meetings with architects, engineers, customers, and city agencies. Financial Performance • Own job costing, billing projections, margin protection, and monthly pay application submissions., • Generate and submit accurate monthly requisitions; target first-submission approval through disciplined, well-documented billing., • Review cost reports and budget vs. actual regularly with the APM. Identify variances early and take corrective action., • Track and protect project margin through every phase of work. Change Order Management • Own the complete change order process: identify the trigger, price the work, review and approve the CO document prepared by the APM, send the formal request to the client, and ensure the approved amount is billed accordingly., • All change order communication with the client runs through the PM. No one in the field discusses scope changes or extra work with the client — a verbal agreement in the field without a PM-approved change order is a liability., • Submit formal time extension requests to the client for all approved change orders where schedule impact exists. Contract & Scope Management • Own all contract requirements and scope obligations from award through final completion., • Lead the internal contract document review process and translate contract scope into actionable construction tasks for the field team., • Identify and resolve scope gaps, RFIs, and scope change triggers before they become issues in the field. Schedule Ownership • Own the master project schedule: milestones, critical path dates, and ongoing updates throughout construction., • Submit 2-week look-aheads to the GC and review schedule health weekly with the Site Superintendent., • Hold the team accountable to schedule milestones and escalate risks proactively. Buyout & Purchasing • Own the full purchasing process for equipment and subcontractors: prepare scope of work documents, solicit and level competitive bids, prepare award recommendations, and obtain required approvals., • Coordinate with the APM on purchase order preparation, vendor follow-up, and delivery tracking., • Structure purchasing to maximize leverage — package multi-property or multi-scope buys where possible. Subcontractor Management • Own subcontractor scope leveling, award, contract execution, and on-site performance throughout the project., • Ensure all subcontractors are fully approved before being scheduled on site. Coordinate with the APM and the internal Compliance team to confirm COIs, badging, certified payroll, and all other compliance requirements are met for both subcontractors and internal personnel before work begins. Compliance Oversight • Own project-level compliance as it relates to scope, schedule, and personnel — both internal crews and subcontractors., • Coordinate directly with the internal Compliance team to ensure all prevailing wage, badging, certified payroll, COI, and regulatory requirements are met and current throughout the project., • Ensure compliance status is confirmed for all parties before mobilization and proactively managed through project completion. Safety • Own safety outcomes at the project level. While the Site Superintendent enforces safety standards in the field daily, the PM is accountable for ensuring the safety program is operating effectively across all assigned projects., • Review safety reports, near-miss documentation, and incident reports as they are submitted. Follow up on any identified hazards or corrective actions with the Site Superintendent., • Ensure JHAs are completed in advance of high-risk work sequences and that the field team is resourced to maintain full safety compliance throughout construction. Permits & Inspections Oversight • Own permit strategy, stamped drawing review, and inspection readiness across all permit types required for the project., • Coordinate with the APM, in-house expeditor, and licensee to ensure all permits are tracked, filed, tested, and inspected on schedule. Commissioning & Closeout • Own startup readiness, service handoff, and final billing. Communicate a clear written plan to the client in advance of all startup activities., • Run the project Handoff Meeting and ensure the complete closeout package — O&Ms, warranties, as-builts, and all required documentation — is assembled before releasing retainage. Team Leadership • Lead and mentor the assigned APM. Delegate administrative responsibilities clearly and hold the APM accountable to their role., • Conduct weekly project reviews with the Site Superintendent covering schedule, cost, field issues, compliance, and safety., • Ensure the field team has everything they need to execute: scope clarity, material readiness, and schedule alignment., • Participate in operational reviews with leadership and contribute to pipeline forecasting by providing accurate project revenue and completion projections. What Success Looks Like in This Role • Projects complete on schedule, on budget, and billing on time — with no surprises to the client., • First-submission requisition approval is the norm, not the exception., • Every change order is identified, priced, and submitted before the work is performed., • The APM is fully operational, the Site Super is aligned, and the PM is not in the field doing tasks that belong to others., • The PM hears about problems from the field first — not from the GC or client. Requirements & Qualifications Required • 5+ years of experience in construction project management focused on mechanical, plumbing, or MEP installations, • Strong knowledge of commercial boiler systems, steam and hydronic heating, domestic hot water, pumps, gas/fuel systems, and applicable NYC mechanical and plumbing codes, • Demonstrated experience owning job financials: pay applications, cost tracking, billing projections, • Experience managing subcontractors: scope leveling, award, compliance, and on-site performance, • Proficiency with project management and field management software (Asana, BuildOps preferred), • Strong written and verbal communication; able to interface with clients, GC partners, engineers, and field crews, • Highly organized, detail-oriented, and proactive — able to manage multiple active projects simultaneously, • Ability to make independent decisions and keep projects moving without waiting to be asked Preferred • Engineering background (MEP, Civil, or related), • Experience on prevailing wage, NYCHA, or affordable housing compliance projects, • Familiarity with DOB permitting processes in NYC What We Offer • Competitive salary commensurate with experience, • Project-based performance bonuses, • Medical, Dental, Vision, Life, and Disability insurance, • 401(k) with company matching (100% match up to 3%, 50% on the next 2%), • 10 days paid vacation, 7 sick days, and paid holidays, • A collaborative, high-performance team environment with direct visibility to leadership, • Opportunity to grow into a Senior PM or leadership role as the company expands Dual Fuel Company LLC is an Equal Opportunity Employer.

Job Title: Manufacturing Engineer Location: Yonkers, NY Shift: 1st Shift (Monday – Friday) Pay Rate: $92-102K annually (commensurate with experience) Type: Direct Hire The Manufacturing Engineer provides critical support to the Production Engineering Manager for all aspects of manufacturing planning and execution. This position plays a key role in researching, designing, and analyzing production specifications and plant capacity to determine the most efficient manufacturing processes. The role involves planning, preparing, and issuing manufacturing documentation that anticipates and coordinates with production sequences. The engineer will plan, schedule, and coordinate the manufacture of jigs, fixtures, and production aids based on requirements of production sequences. They will also develop and update procedures for the construction and modification of these items as needed. Additional responsibilities include designing, evaluating, and maintaining mechanical products, equipment, systems, and processes to ensure operational efficiency, safety, and compliance with engineering principles. The Manufacturing Engineer will also be responsible for estimating project costs, preparing bids, and coordinating with internal teams to ensure the timely completion of engineering objectives. Essential Functions • Provide engineering support for production planning, manufacturing process development, and efficiency improvements., • Research, plan, and schedule manufacture of jigs, fixtures, and production aids; develop construction and modification procedures as required., • Research, design, install, and maintain mechanical products and systems to meet performance and safety requirements., • Develop and test alternate designs and processing methods to evaluate feasibility, cost, and efficiency., • Estimate costs and prepare bids and contract documents for engineering and production projects., • Use SolidWorks and AutoCAD for computer-assisted design and development of production (shop) drawings., • Create and revise production drawings (detail and assembly)., • Draft detailed multiview drawings for individual components and assemblies., • Create DXF files for CNC programming and manage related files., • Maintain organized file systems for production and engineering documentation. Job Specifications • Minimum of five (5) years’ experience in plant engineering or production planning., • Bachelor of Science degree in Mechanical or Electrical Engineering, or equivalent technical education and experience., • Strong proficiency with SolidWorks, AutoCAD, and mechanical drafting., • Understanding of manufacturing processes, CNC operations, and tooling design., • Excellent analytical, communication, and organizational skills., • Proven ability to manage multiple projects simultaneously in a production-focused environment., • Hands-on approach to problem-solving and continuous improvement initiatives. Work Environment • Primarily works in a manufacturing and production engineering environment., • Involves collaboration with production, quality, and design departments., • Requires standing, walking, or visiting production areas as needed., • Must comply with all safety protocols and wear appropriate PPE when on the shop floor. Candidate Fit: This candidate is a strong fit for Manufacturing Engineer positions across Aerospace, Automotive, Bus, Truck, and Industrial Manufacturing industries. They bring proven experience in SolidWorks, AutoCAD, and CNC programming, combined with a deep understanding of machining practices, fixture design, and production process optimization. Skilled at coordinating engineering projects from concept to production, they excel in improving workflow efficiency, cost reduction, and product quality through precise planning and cross-department collaboration. Their background includes developing jigs, tooling, and production layouts, performing root cause analysis, and driving continuous improvement initiatives within fast-paced manufacturing environments. Known for hands-on technical leadership and a data-driven mindset, they consistently deliver practical engineering solutions that align with safety, quality, and performance standards. Company Overview Founded in 2010, Top Prospect Group was created with a focus on matching high-quality candidates with top-tier clients while fostering an environment where success is shared by all. In 2023, the company was acquired by HW Staffing Solutions, expanding its service offerings to include technology, engineering, and professional services. Qualified candidates are encouraged to apply immediately! Please include a clean copy of your resume, salary expectations, and availability with your application.

Verde Electric Corp is seeking an experienced Fleet Manager to oversee and manage a commercial fleet of 150+ trucks and vehicles. This is a hands-on management position responsible for ensuring the fleet is safe, reliable, compliant, properly maintained, and available to support the company's daily operations. The Fleet Manager will oversee vehicle maintenance and repairs, preventive maintenance programs, regulatory compliance, fuel management, fleet-related purchasing, vendor relationships, vehicle replacement, and fleet operating costs. The ideal candidate will have significant experience managing a large commercial fleet and be comfortable working with drivers, mechanics, operations management, outside vendors, and senior leadership. Fleet Operations · Manage the company's fleet of 150+ trucks and vehicles. · Maintain accurate records for all vehicles, including maintenance, inspections, registrations, titles, mileage, and repair history. · Monitor vehicle utilization, availability, downtime, and operating costs. · Establish procedures to maximize fleet reliability and minimize vehicle downtime. · Coordinate vehicle assignments, replacements, transfers, and disposal. Maintenance & Repairs · Develop and manage a comprehensive preventive maintenance program. · Schedule routine service, inspections, repairs, and emergency maintenance. · Monitor vehicle condition and identify issues before they become major repairs. · Manage relationships with dealerships, repair facilities, mobile mechanics, parts suppliers, and other vendors. · Review and approve repair estimates and invoices. · Negotiate pricing and service agreements with outside vendors. · Track maintenance costs by vehicle and identify opportunities to reduce expenses. Safety & Regulatory Compliance · Ensure all vehicles are properly inspected, registered, insured, and maintained. · Manage initial vehicle registrations and timely registration renewals for all fleet vehicles. · Maintain and update insurance coverage and documentation for all company vehicles and equipment. · Prepare and submit the annual diesel emissions inventory report. · Maintain compliance with applicable DOT, FMCSA, OSHA, state, and local requirements, as applicable to the company's operations. · Maintain required vehicle and driver documentation. · Coordinate DOT inspections and ensure deficiencies are corrected promptly. · Work closely with the company's safety department to address fleet-related safety issues. · Monitor accident and vehicle damage reports and coordinate repairs and claims. Financial & Administrative Management · Develop and manage the annual fleet maintenance and operating budget. · Track fuel, maintenance, parts, repairs, and other fleet-related expenses. · Manage quarterly Highway Use Tax (HUT) filings and payments. · Manage annual Heavy Highway Vehicle Use Tax filings and renewals. · Maintain and administer the fleet fuel card program, including card issuance, updates, account maintenance, and usage monitoring. · Manage International Fuel Tax Agreement (IFTA) reporting and filings, including maintenance of fuel purchase and mileage records. · Identify cost-saving opportunities without compromising safety or reliability. · Review vendor invoices for accuracy and proper authorization. · Provide regular fleet performance and expense reports to management. Fleet Acquisition & Replacement · Assist management in determining vehicle replacement schedules. · Research truck specifications and recommend appropriate vehicles for company operations. · Obtain and compare pricing from dealers and manufacturers. · Coordinate the acquisition, upfitting, delivery, registration, and deployment of new vehicles. · Manage the sale or disposal of retired vehicles. Qualifications · 5+ years of fleet management experience, preferably managing 100+ commercial vehicles. · Experience with trucks and commercial vehicles strongly preferred. · Knowledge of DOT/FMCSA regulations and commercial vehicle compliance. · Strong knowledge of preventive maintenance and vehicle repair. · Experience managing outside repair facilities and vendors. · Strong organizational and record-keeping skills. · Ability to manage multiple priorities in a fast-paced operating environment. · Strong communication and negotiation skills. · Proficiency with fleet management software and Microsoft Office. · Valid driver's license with a clean driving record. Preferred Experience · Experience managing a 150+ vehicle construction, electrical, utility, transportation, or similar commercial fleet. · Experience with pickup trucks, service trucks, vans, trailers, and heavy-duty vehicles. · Experience with fleet telematics/GPS and fuel-management systems. · Experience managing vehicle acquisition and replacement programs. · Experience managing fleet budgets and reducing operating costs. What We Offer · Competitive salary based on experience. · Performance-based compensation. · Company benefits package. · Paid time off and holidays. · [401(k) / Health Insurance / Other Benefits] · Opportunity to play a key role in managing and improving a large company fleet. How to Apply Please submit your resume to nestatico@verdeelectric.com rdileonardo@verdeelectric.com

Job Description Employment Type: Full-Time FSLA: Hourly/Non-Exempt Division: Riggs Department: Riggs Reports to: Labor Foreman / Project Manager Supervisory Duties: No Salary Range: $20 - $25/hour Construction Laborers are responsible for assisting with the maintenance, cleanliness, and safety of construction sites. This includes debris removal, general upkeep, and supporting other trades as needed. Reporting directly to the Labor Foreman or Project Manager, this position plays a critical role in maintaining job site efficiency and safety, and must consistently follow all company safety protocols. Responsibilities / Essential Functions • Load and unload materials, assist carpenters and equipment operators, and perform general site tasks as directed., • Clean and prepare construction sites, including setting up and dismantling scaffolding, and removing debris and waste in accordance with site safety standards., • Maintain a clean and organized job site by storing materials properly, removing tools and equipment when not in use, and securing the area daily., • Use equipment or perform manual labor to load and unload construction supplies from trucks., • Follow instructions from blueprints or site supervisors., • Work with materials including wood, drywall, plastic, and fiberglass., • Perform tasks at heights, including working on ladders, stilts, scaffolding, and structural beams., • Conduct regular checks to ensure all work meets building codes and project specifications., • Operate a range of tools and equipment, including power drills, demolition saws, skid steers, forklifts, sanders, hoists, and hand tools., • Shovel materials such as asphalt, concrete, dirt, and snow as required., • Strictly adhere to all safety procedures and report any safety concerns or violations immediately., • Report any incidents or injuries promptly to the Safety Director, Foreman, or HR following company reporting procedures. Key Skills • Strong work ethic and reliability, • Punctual and dependable, • Willingness to follow instructions and learn on the job, • Ability to work both independently and as part of a team, • Maintains professionalism on site, • Flexible and able to work overtime as needed, • Committed to safety and attention to detail Required Experience • Minimum 1 year of experience in construction or a related field., • Ability to lift at least 50 pounds and stand for extended periods., • Valid driver’s license and reliable transportation; must be willing to travel to job sites., • Must be 18 years of age or older., • High school diploma or equivalent preferred.

Job Description Beware of Recruitment Fraud: We are committed to protecting job seekers from recruitment fraud. Please be aware that all official communication regarding opportunities with our firm will come exclusively from an email address ending in @RoseNYC.com. We will never request payment, financial information, or sensitive personal documentation during the application process, and we will never extend a job offer without first conducting a formal in-person interview. If you receive a message that appears suspicious or does not originate from this domain, please mark it as spam or phishing and report it to us directly at recruiting@rosenyc.com. Overview Rose Associates is a recognized market leader in multifamily and mixed-use real estate. Based in New York City, we own, develop and operate leading properties in urban markets from Philadelphia to Boston and across all residential asset classes, including market, regulated, workforce and affordable housing. Our dynamic services platform spans development, construction, property and asset management, leasing, marketing and accounting/financial operations. We partner with private owners and institutional investors globally to develop and operate some of the most iconic assets in our markets. We rely on technology and the deep expertise of our team to consistently outperform the market in the operation of more than 30,000 units across some 250 properties in the most challenging housing markets in the country. For the past three years, Rose has been the top-rated manager for resident satisfaction in the United States on the Kingsley Surveys platform (peer group of firms with 10-30,000 units being surveyed). Established in 1925, Rose Associates possesses a century of real estate expertise and an impeccable reputation for excellence and integrity. Today a woman-owned business led by CEO Amy Rose, we are committed to a corporate culture of belonging and inclusion that is widely admired in the industry. As we expand across the Northeast, Rose is providing opportunity for our team members to grow their careers in an environment of respect and support. Join us on the forefront of innovation and growth – Rose Associates is where excitement meets opportunity! We are searching for a vibrant and experienced Maintenance Manager to oversee daily operations in our residential rental community. Your responsibilities will include managing the building services team, ensuring staff performance, and maintaining resident satisfaction and financial success. We're on the lookout for a candidate who demonstrates exceptional leadership, adept problem-solving, and efficient multitasking. Clear communication, a solid grasp of building mechanical infrastructure, and strong organizational skills are key. The role also involves overseeing expenses, managing contractor performance, ensuring building compliance, monitoring systems, and implementing preventative maintenance for optimal building performance and resident contentment. If you're ready to take charge in a dynamic environment, apply now to be our Resident Manager. Essential Job Functions • Manage daily property operations, • Prioritize tenant concerns, and ensure timely maintenance, • Coordinate preventive maintenance, oversee compliance with audits and local laws, and manage repairs by obtaining vendor quotes and scheduling tasks., • Implement corporate maintenance procedures, coordinate with contractors, negotiate and manage service contracts, and ensure compliance with quality, safety, and legal standards., • Assist in budget development and management for building maintenance, regularly review variances, control expenditures, identify cost savings, and prepare reports for management., • Respond to building emergencies, supervise construction projects, enforce safety protocols, conduct inspections and training, and maintain accurate records, including investigating and reporting accidents/incidents., • Oversee and assess staffing requirements within the building, ensuring optimal workforce management., • Must be present on-site and be able to move throughout the building to address building related matters and meet with tenants, staff, vendors and visitors., • Ability to ascend and descend stairs, as well as positioning oneself in small spaces for building inspections and maintenance repairs and lifting and moving large or heavy objects in excess of 50 pounds., • Must be comfortable with exposure to varying environmental climates and circumstances., • Proficiency in navigating computers and property management software, to include Microsoft Office and Yardi., • Required to respond to emergencies and be on call 24 hours. Qualifications • A minimum of 4 years in maintenance and staff management, strong self-management skills, professional demeanor., • Experience opening a new construction, lease-up building is required, along with accepting units from construction., • Optimize building efficiency with sustainable energy practices, grid interactive maintenance, and modern security technologies., • Proficient in various mechanical systems for cost-effective solutions., • Possess the required licenses and certificates (Certificate of fitness S12, Certificate of fitness S-13 Certificate of fitness S-95, Certificate of fitness P-99, EPA 608 Universal)., • Strong communication skills with staff, property management teams, and senior management., • Work authorization (required)Annual salary range - $95,000 - $110,000 Powered by JazzHR 7opLTw07rv

Job Description Job Title: Assistant Project Manager 1 Who we are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. Summary/Objective: The Assistant Project Manager (APM 1) will serve as a vital team member assisting the Senior Project Manager/Project Manager on the full scope of the project. The APM 1 will be responsible for Document Control & Procurement Management, Communication, Cost Management, Subcontractor Coordination and Project Reporting while representing Callahan Construction Managers throughout the full project cycle. The APM 1 will also have oversight in managing the Project Administrators on task completion. The APM must exhibit time management skills and prioritize their work based on the daily needs of the project. Essential Functions: Safety -Coordination of Safety Program compliance in conjunction with the Superintendent -Shadow Safety Inspectors on site visits -Conduct 4 (minimum) independent safety inspections per month -Assist / Participate in all safety related activities and always promote a safety culture Document Control & Procurement Management -Understand the Plans, Specifications and Contracts of the project -Review of shop drawings and samples for compliance with contract documents -Coordination of meetings with Owners / Architect / Engineer and producing quality meeting minutes and meeting package content all in a timely manner -Manage all RFIs and Submittals utilizing Viewpoint with consultants, subcontractors, and field staff -Manage updates of the current construction document set utilizing Procore -Distribute information to subcontractors/suppliers -Reviewing and tracking material deliveries as scheduled and expediting in conjunction with the Project Superintendent to ensure on-time procurement Communication -Develop and maintain positive relationships with the Owner, Subcontractors and Project Team -Coordinate and communicate updates and changes to the schedule of the project. -Control the prompt flow of information to field team, subcontractors, and suppliers Cost Management -Participate in subcontractor buyout and subcontract issuance -Compile all changes in the project. Vet pricing on all change requests and submit proposals with time extensions as needed; Reviewing with Project Manager prior to submission. -Proficient in project accounting processes to ensure prompt payments of requisitions & Invoices -Review of monthly Subcontractor requisition and material invoices with your manager -Compile field tickets from Superintendent and attach to all material invoices processed Project Management and Reporting -Distribute Punchlist for execution -Participate in the monthly schedule update meeting -Preparing and submitting of the “Monthly Report” to the project team with guidance from your manager and Superintendent -Preparation of Quarterly cost meetings -Competing the Closeout of the project with the Owner and Subcontractors -Compile permit closeout and turnover documents -Maintain all records and files -Operations and Maintenance Manuals -Financial Closeout with PM and Accounting People Management -Oversee the Project Administrator tasks which include compliance log, subcontractor insurance, subcontractor change proposal tracking, subcontractor change order execution, EEO/MBE/WBE Required education and experience: -Bachelor’s Degree (Preferably Engineering, Construction Management or Architecture) -0-5 Years experience -Prior experience in construction settings All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color religion, sex, sexual orientation, gender identity, national original or on an applicant’s status as a protected veteran or as individual with a disability.

Job Description Job Title: Field Operations Intern Employment Type: Intern Division: Field Operations Department: Field Operations Work Schedule: Full-time/40-hours - In Person Salary Range: $24 - $29/hour The Field Operations Intern supports Superintendents and Project Managers by assisting with safety program administration, quantity tracking, schedule analysis, and job site documentation. This role offers hands-on experience in field coordination, schedule management, and construction quality within a dynamic construction environment. Responsibilities / Essential Functions • Support the administration of the project safety program to ensure a safe and compliant work environment., • Provide technical assistance by interpreting contract drawings, submittals, and project documentation., • Assist the assistant superintendent, superintendent, and project manager with daily and weekly activities, including preparing daily reports, conducting safety walks, compiling quantity reports, and updating project schedules., • Develop a clear understanding of the overall project schedule, including critical path analysis., • Review and contribute to the short-term planning process to ensure project milestones are met., • Participate in the quality assurance program by attending meetings, performing site inspections, and verifying materials for compliance with project specifications., • Coordinate subcontractor activities to support adherence to project timelines and safety requirements., • Maintain project documentation such as daily logs, RFIs, and submittal tracking to support effective communication and record-keeping., • Monitor onsite material deliveries and inventory to facilitate uninterrupted project progress., • Participate in project team meetings, communicating updates, challenges, and potential solutions., • Observe and report site conditions that could impact schedule, cost, or safety., • Utilize construction management software and tools to accurately track and update project information. Key Skills • Strong written and verbal communication skills to clearly convey information and coordinate with team members, clients, and subcontractors., • Demonstrated interest in construction management and the construction industry., • Proactive problem-solving abilities with an analytical mindset and excellent attention to detail for tracking schedules, quantities, and quality inspections., • Effective time management and prioritization skills to handle multiple tasks and meet deadlines in a fast-paced environment., • Strong organizational skills to manage project documentation and communications., • Ability to work independently and collaboratively within team environments., • Adaptable and eager to learn, with a team-oriented approach to support multiple stakeholders and address site challenges proactively. Required Experience • Currently pursuing a Bachelor’s degree in Construction Management, Engineering, or related field; preference for Civil Engineering or construction-focused programs., • Basic knowledge of construction site safety standards, practices, and protocols., • Proficient in Microsoft Office Suite (Excel, Word, Outlook) with aptitude for learning construction management software., • Ability to read and interpret construction drawings, submittals, and technical documents., • Strong organizational skills for managing documentation and reporting., • Basic understanding of construction scheduling, including critical path method (CPM) concepts.

Job DescriptionAbout OPAL Fuels OPAL Fuels (Nasdaq: OPAL) is a leader in the capture and conversion of biogas into low carbon intensity RNG and renewable electricity. OPAL Fuels is also a leader in the marketing and distribution of RNG to heavy duty trucking and other hard to de-carbonize industrial sectors. For additional information, and to learn more about OPAL Fuels and how it is leading the effort to capture North America’s naturally occurring methane and decarbonize the economy, please visit www.opalfuels.com. Position Summary: The HR Business Partner is a hands-on HR advisor responsible for supporting people practices aligned with business priorities across OPAL Fuels’ renewable natural gas, fuel station services, and corporate functions. Based in White Plains, NY, this role reports to the Chief Human Resources Officer and partners with assigned business groups to support employee relations, workforce planning, performance management processes, HR compliance, onboarding, leave management, and culture-building in a fast-growing, safety-focused energy business. Role Structure and Coverage Model We are hiring two HR Business Partners. One will will provide HR business partnership support to Operations and Corporate Functions which includes RNG Plant operations, Finance, Human Resources, Legal and Communications. The other will support Sales and Operations which includes Fuel Station Sales Team and Fuel Station Services and Construction teams. This coverage model requires close partnership with operational and corporate leaders and their teams. Duties and Responsibilities: • Serve as a trusted HR partner to assigned business groups, translating operating needs into practical people solutions that support engagement, productivity, retention and organizational capability., • Support workforce planning for assigned client groups, including headcount planning, talent risk identification, organizational needs assessment and capability-building activities., • Partner with leaders on employee relations matters, performance improvement, investigations, policy interpretation and conflict resolution while promoting fairness, consistency and compliance., • Support managers with effective communication, feedback, accountability, change adoption and employee development practices., • Support annual and mid-year performance management processes, including goal setting, calibration, performance conversations and follow-through on development plans., • Partner with Talent Acquisition to define hiring priorities, strengthen selection decisions and ensure onboarding plans create early impact for new hires., • Administer onboarding and offboarding processes for talent across assigned client groups, ensuring a consistent employee experience, timely completion of required documentation and effective coordination with managers and HR partners., • Administer all leave management processes, including workers’ compensation management, claim intake coordination, required documentation, follow-up with employees, managers and carriers, and coordination to support timely case resolution, compliance and return-to-work planning., • Use HR metrics and business data to identify trends, assess organizational health and recommend actions related to turnover, staffing, engagement, absenteeism, productivity and capability gaps., • Collaborate with HR colleagues on compensation, benefits, learning and development, talent acquisition and policy deployment., • Provide back up coverage for all areas of HR including payroll administration, • Champion OPAL Fuels’ culture, values, safety mindset and commitment to execution across geographically dispersed field, operational and corporate teams., • Support change initiatives related to growth, process improvement, restructuring, integration, technology adoption and business transformation.Qualifications and Skills:, • Bachelor’s degree in Human Resources, Business Administration, Organizational Development or a related field required; master’s degree or HR certification preferred., • 7+ years of progressive HR experience, including HR business partner experience supporting operational, field-based or multi-site employee populations., • Demonstrated experience supporting workforce planning, employee relations, organizational effectiveness and change management activities., • Strong working knowledge of employment law, HR policies, performance management, investigations and employee relations best practices., • Experience supporting industrial, energy, construction, logistics, field service, manufacturing or infrastructure-related workforces preferred., • Preferred experience in both large multinational corporations and small start-up enterprises, with broad exposure across HR responsibilities including payroll, compensation, benefits, talent acquisition, learning and development, and HR systems implementation., • Ability to travel as needed to support assigned business groups, field locations and HR priorities. Critical Competencies, • Strategic thinking with practical execution discipline, • Business acumen and ability to understand operational drivers, • High judgment, discretion and credibility with employees and managers, • Strong coaching, influencing and conflict-resolution skills in a business partnership context, • Analytical mindset with the ability to convert HR data into action, • Comfort working in a fast-paced, growing and geographically dispersed environment, • Commitment to safety, compliance, inclusion and continuous improvement, • Flexible, resilient and open to jump in and help in all areas of HR when needed. Success Measures, • Improved manager capability within assigned client groups, • Reduced avoidable turnover and stronger retention of critical talent, • Timely resolution of employee relations matters with consistent application of policy and sound judgment, • Improved workforce planning discipline and succession visibility, • Higher engagement, stronger communication and clearer accountability across supported groups, • Measurable progress against business-specific HR priorities and operating goals Work Hours and Arrangements: This position operates Monday–Friday during standard business hours. This role is expected to work on site at least 3 days per week. This requirement may change based on business needs. Physical requirements: The physical demands described are representative of those that must be met by an employee to successfully perform the essential functions of this job. Reasonable accommodation may be made to enable individuals with disabilities to perform the essential functions. Work is performed in an office environment and requires the ability to operate standard office equipment and keyboards. Position requires substantial movements of the wrists, hands, and/or fingers as necessary. Employee is required to perform activities such as preparing and analyzing data and figures; transcribing; viewing a computer terminal, and extensive reading. Must be able to remain in a stationary position for an extended period. Job Type: Full-time Pay: The range for this role is anticipated to be $120,000-$140,000 annually with bonus for eligible positions. Where a specific pay range is noted, it is a good faith estimate at the time of this posting. The actual salary offered will be based on experience, skills, qualifications, market / business considerations, and geographic location. Benefits: • Health Insurance, • Dental Insurance, • Vision Insurance, • Life Insurance, • Short & Long Term Disability, • 401(k) plus Matching Contributions, • Tuition Assistance, • Referral Bonus, • Generous Paid Time Off, • Ten Paid Holidays OPAL Fuels LLC is an equal opportunity employer and all qualified applicants will receive consideration for employment without regard to race, color, religion, creed, national origin or ancestry, ethnicity, sex (including gender, pregnancy, sexual orientation, and gender identity), age, physical or mental disability, citizenship, past, current, or prospective service in the uniformed services, genetic information, or any other characteristic protected under applicable federal, state, or local law. OPAL Fuels does not accept unsolicited resumes from third-party recruiters or agencies without a current signed agreement and written confirmation specifying the roles for which submissions are authorized. Any resumes submitted without an agreement and authorization will be considered the property of OPAL Fuels. Powered by JazzHR UeReNkaukU

Job Description Summary/objective: The Safety Manager provides leadership and guidance to assigned projects in the development and implementation of safety and health processes. Who we are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. Essential functions: • Develops and implements an effective site-specific safety plan in conjunction with the Project Manager and management team, • Manages the coordination of the safety and health subcontractor, vendor and owner personnel working on company project, • Oversees and coordinates project safety programs with subcontractors, • Assists in planning and coordinating work to minimize risks, and aggressively manage losses involving injuries or property damages, • Directs quarterly comprehensive on-site safety audits, • Inspects and evaluates the project site, equipment and processes for compliance with applicable local, state and federal regulations, as well as company and owner policies and procedures, • Conducts accident investigations and completes incident reporting for project management, • Accompanies injured employees to treatment and medical evaluation. Ensures all safety protocols are followed, • Advises Project Management on Industrial Hygiene protocols: performs environmental monitoring, • Provides training and education to company personnel regarding safety requirements, including coordination of the new hire safety orientation programs, • Completes and provides weekly safety update to the Director of Safety, • Direct and attend toolbox talk Required education and experience: • Bachelor’s Degree in Safety, Industrial Hygiene, Civil Engineering, Construction Management or related field, • 5+ years of experience in Construction Management or related field, • OSHA 30-hour trained, • First Aid/CPR certified, • Be highly motivated to continue growing in the safety field, • Proficiency with PC computers and software, including Microsoft Office, Bluebeam, and Procore Preferred education and experience: • CHST Preferred All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color religion, sex, sexual orientation, gender identity, national original or on an applicant’s status as a protected veteran or as individual with a disability.

Job Description Beware of Recruitment Fraud: We are committed to protecting job seekers from recruitment fraud. Please be aware that all official communication regarding opportunities with our firm will come exclusively from an email address ending in @RoseNYC.com. We will never request payment, financial information, or sensitive personal documentation during the application process, and we will never extend a job offer without first conducting a formal in-person interview. If you receive a message that appears suspicious or does not originate from this domain, please mark it as spam or phishing and report it to us directly at recruiting@rosenyc.com. Overview Rose Associates is a recognized market leader in multifamily and mixed-use real estate. Based in New York City, we own, develop and operate leading properties in urban markets from Philadelphia to Boston and across all residential asset classes, including market, regulated, workforce and affordable housing. Our dynamic services platform spans development, construction, property and asset management, leasing, marketing and accounting/financial operations. We partner with private owners and institutional investors globally to develop and operate some of the most iconic assets in our markets. We rely on technology and the deep expertise of our team to consistently outperform the market in the operation of more than 30,000 units across some 250 properties in the most challenging housing markets in the country. For the past three years, Rose has been the top-rated manager for resident satisfaction in the United States on the Kingsley Surveys platform (peer group of firms with 10-30,000 units being surveyed). Established in 1925, Rose Associates possesses a century of real estate expertise and an impeccable reputation for excellence and integrity. Today a woman-owned business led by CEO Amy Rose, we are committed to a corporate culture of belonging and inclusion that is widely admired in the industry. As we expand across the Northeast, Rose is providing opportunity for our team members to grow their careers in an environment of respect and support. Join us on the forefront of innovation and growth – Rose Associates is where excitement meets opportunity! We are searching for a vibrant and experienced Maintenance Manager to oversee daily operations in our residential rental community. Your responsibilities will include managing the building services team, ensuring staff performance, and maintaining resident satisfaction and financial success. We're on the lookout for a candidate who demonstrates exceptional leadership, adept problem-solving, and efficient multitasking. Clear communication, a solid grasp of building mechanical infrastructure, and strong organizational skills are key. The role also involves overseeing expenses, managing contractor performance, ensuring building compliance, monitoring systems, and implementing preventative maintenance for optimal building performance and resident contentment. If you're ready to take charge in a dynamic environment, apply now to be our Resident Manager. Essential Job Functions • Manage daily property operations, • prioritize tenant concerns, and ensure timely maintenance, • Coordinate preventive maintenance, oversee compliance with audits and local laws, and manage repairs by obtaining vendor quotes and scheduling tasks., • Implement corporate maintenance procedures, coordinate with contractors, negotiate and manage service contracts, and ensure compliance with quality, safety, and legal standards., • Assist in budget development and management for building maintenance, regularly review variances, control expenditures, identify cost savings, and prepare reports for management., • Respond to building emergencies, supervise construction projects, enforce safety protocols, conduct inspections and training, and maintain accurate records, including investigating and reporting accidents/incidents., • Oversee and assess staffing requirements within the building, ensuring optimal workforce management., • Must be present on-site and be able to move throughout the building to address building related matters and meet with tenants, staff, vendors and visitors., • Ability to ascend and descend stairs, as well as positioning oneself in small spaces for building inspections and maintenance repairs and lifting and moving large or heavy objects in excess of 50 pounds., • Must be comfortable with exposure to varying environmental climates and circumstances., • Proficiency in navigating computers and property management software, to include Microsoft Office and Yardi., • Required to respond to emergencies and be on call 24 hours. Qualifications • A minimum of 4 years in maintenance and staff management, strong self-management skills, professional demeanor., • Experience opening a new construction, lease-up building is required., • Optimize building efficiency with sustainable energy practices, grid interactive maintenance, and modern security technologies., • Proficient in various mechanical systems for cost-effective solutions., • Possess the required licenses and certificates (Certificate of fitness S12, Certificate of fitness S-13 Certificate of fitness S-95, Certificate of fitness P-99, EPA 608 Universal)., • Strong communication skills with staff, property management teams, and senior management., • Work authorization (required)Annual pay range - $80,000 - $85,000 Powered by JazzHR 9A84XzPYSL

Job DescriptionBeware of Recruitment Fraud: We are committed to protecting job seekers from recruitment fraud. Please be aware that all official communication regarding opportunities with our firm will come exclusively from an email address ending in @RoseNYC.com. We will never request payment, financial information, or sensitive personal documentation during the application process, and we will never extend a job offer without first conducting a formal in-person interview. If you receive a message that appears suspicious or does not originate from this domain, please mark it as spam or phishing and report it to us directly at recruiting@rosenyc.com. Overview Rose Associates is a recognized market leader in multifamily and mixed-use real estate. Based in New York City, we own, develop and operate leading properties in urban markets from Philadelphia to Boston and across all residential asset classes, including market, regulated, workforce and affordable housing. Our dynamic services platform spans development, construction, property and asset management, leasing, marketing and accounting/financial operations. We partner with private owners and institutional investors globally to develop and operate some of the most iconic assets in our markets. We rely on technology and the deep expertise of our team to consistently outperform the market in the operation of more than 30,000 units across some 250 properties in the most challenging housing markets in the country. For the past three years, Rose has been the top-rated manager for resident satisfaction in the United States on the Kingsley Surveys platform (peer group of firms with 10-30,000 units being surveyed). Established in 1925, Rose Associates possesses a century of real estate expertise and an impeccable reputation for excellence and integrity. Today a woman-owned business led by CEO Amy Rose, we are committed to a corporate culture of belonging and inclusion that is widely admired in the industry. As we expand across the Northeast, Rose is providing opportunity for our team members to grow their careers in an environment of respect and support. Join us on the forefront of innovation and growth – Rose Associates is where excitement meets opportunity! We're on the lookout for a visionary leader to join our dynamic team as Associate Director of Multifamily Operations. In this pivotal role, you'll spearhead the operational excellence for select properties within our multifamily portfolio, actively contributing to strategic planning and guaranteeing the overall success of our residential communities. If you're ready to make a significant impact and lead with innovation, we invite you to apply to be part of our exciting journey! Essential Job Functions • Collaborate with property managers to optimize daily operations, implement financial strategies, and monitor budgets, including analyzing monthly financial performance, rent variations, and staying informed about market intelligence., • Prepare owner reporting packages, incorporating budgets, business plans and monthly owner reports., • Deliver effective leadership and mentorship to ensure high performance and foster a collaborative work environment among property management teams., • Provide comprehensive asset management support, overseeing acquisitions and dispositions, and communicate relevant information and key issues effectively to ownership., • Contribute to the development and execution of strategic plans, addressing escalated resident concerns, and identifying growth opportunities for enhanced satisfaction., • Collaborate with the marketing team to ensure accuracy and adjust marketing plans as necessary., • Review leasing, occupancy activity, and approve resident retention and renewal programs to meet budget/proforma expectations., • Collaborate across departments to efficiently achieve property goals., • Ensure strict compliance with legislation, regulations, and safety standards., • Proactively manage assigned communities, conducting frequent site visits and inspections to ensure property upkeep and compliance, preserving their integrity., • Uphold compliance with company policies, government regulations and Fair Housing., • Review and inspect all Capital Replacement Plans., • Manage recruitment and retention of site employees, ensuring training milestones and requirements are met., • Must be present on-site and be able to move throughout the buildings to address community-related matters, including exceptional communication skills to meet with tenants, staff, vendors and visitors., • Ability to travel between the main office and site locations within the portfolio and be able to ascend and descend stairs, including comfortability with exposure to varying environmental climates and circumstances., • Ability to perform the essential duties and responsibilities of the position in residential environments where domestic pets are routinely present. Employees are required to work in common areas, lobby areas, building offices, amenity spaces, and occupied residential apartments where pets may be present while carrying out the responsibilities of their position. Depending on the role, these responsibilities can include responding to resident requests and work orders; providing concierge and resident services; entering apartments; conducting inspections; performing maintenance, repairs, and other handyperson duties; managing building operations; supervising or coordinating building staff, vendors, and contractors; responding to emergencies; and performing other resident management and property-related responsibilities. The ability to perform the essential functions of the position in areas where domestic pets are present, including occupied residential apartments, is an essential requirement of employment for positions requiring such work, • Position may be required to perform duties outside their normal responsibilities as needed.Qualifications, • Bachelor's degree in a relevant field or equivalent experience., • 10 years of residential property management experience, including a minimum of 7 years in a senior management position., • Proficiency in navigating computers and community management software, to include, • Microsoft Office include iLuvLeasing, On-Site, and Yardi., • Demonstrated ability to supervise staff, manage operational matters, and solve problems., • Excellent organizational, time management, and communication skills., • Strong technical knowledge of building operations and maintenance., • Understanding of marketing trends, budgeting, and reporting, including strong financial skills with knowledge of GAAP., • Work authorization (required)In addition to base compensation, full benefits packages and significant incentive pay are available. Annual salary range: $135,000 - $155,000 Powered by JazzHR zBAkSXKmHJ

Job DescriptionBenefits: • Opportunity for advancement Safety Officer (EHSO) ???? Location: NYC Area (In-Person) ???? Pay: $55.00 – $67.00 per hour (based on experience) ???? Job Type: Full-Time Position Summary We are seeking a qualified Safety Officer to support NYC Transit, Metro-North Railroad and Long Island Railroad construction projects throughout the NYC area. This role is responsible for ensuring all field activities are executed safely, efficiently, and in full compliance with contract requirements and regulatory standards. As the on-site safety authority, you will oversee daily operations, enforce safety protocols, and maintain accurate documentation to support both compliance and project performance. Key Responsibilities Field Oversight: Conduct daily site inspections to ensure contractor compliance with approved plans, safety regulations, and technical specifications • Reporting & Documentation: Prepare detailed Daily Inspection Reports (DIRs), including workforce, work performed, and quantities for payment verification • Financial Oversight: Review and maintain accurate Time & Material (T&M) records to ensure cost transparency and accountability • Project Tracking: Utilize client recording systems to monitor progress, maintain records, and support project controls • Stakeholder Coordination: Act as a liaison between project owners, contractors, utility providers, and regulatory agencies • Safety Leadership: Enforce site-specific safety requirements, environmental regulations, and EHS protocols to promote a zero-incident cultureRequired Qualifications & Certifications Education: Bachelor of Science in Safety, Environmental Health, Industrial Hygiene, or a related discipline • Experience: Minimum 10+ years of experience in railroad health and safety compliance NYC Transit/MTA/LI Railroad project experience strongly preferred • Professional Certification (Required): Must hold at least one: CSP, CIH, or CHST • Required Training & Credentials:, • OSHA 500 Outreach Trainer for Construction, • OSHA 30-Hour for Construction, • 40-Hour NYC DOB Site Safety Manager Course Completed Certificate, • Right of Way experience for MTA agencies including NYC Transit, Metro-North and Long Island Railroad, • SSPC C-3 Lead Training and the appropriate C-5, • NYSDOL Asbestos License Class D, • First Aid/CPR certifications, • 40-Hour Hazardous Waste Worker Training and up-to-date refreshers and supervisory training, • Member of the ASSP, • Undergraduate degree in Safety and Health or related discipline a plus, • Active ASP/and or CST designation a plus, • Technical Skills: Strong technical writing and reporting capabilities Solid understanding of NYC/NYC Transit/LI Railroad construction codes, safety regulations, and environmental compliance standardsWhy Join Us? • Competitive Compensation: $55–$67 per hour based on experience and certifications, • Meaningful Work: Support critical infrastructure and environmental projects across NYC, • Stability: Long-term project opportunities in a high-demand sector, • Work-Life Balance: Accruable Paid Time Off (PTO), • Professional Growth: Work within a safety-focused, compliance-driven environmentWork Environment This is a fully in-person field role requiring regular site presence across active construction environments in the NYC area. Ready to lead safety and compliance on critical NYC infrastructure projects? Apply today.

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Project Management Department: Project Management Reports to: Project Manager Supervisory Duties: Yes Salary Range: $85,000.00 - $124,000.00 The Assistant Project Manager (APM) will serve as a vital team member while assisting the Senior Project Manager and/or Project Manager on all aspects of a project. APM’s will be expected to take on central roles for the oversight of the Project Engineer with a specific focus on document control (RFIs, submittals, material delivery, etc.), subcontractor coordination, design team communication, project reporting and overall representation of Consigli throughout the entirety of the project. Responsibilities / Essential Functions • Serve as a main point of contact for communication with Owners, OPMs and Design Teams members., • Coordinate and provide input during weekly meetings with subcontractors, design teams, and owner representatives to resolve field conflicts and drive resolution., • Support project cost and change management process: prepare reports for review with other team members and present at both Owner and internal meetings., • Assist in development of estimates and bid proposals for both lump sum and GMP projects., • Oversight/Management of Project Engineer and associated responsibilities including document Control, RFIs, Submittals, Material Delivery Tracking and Meeting Minutes., • Mentor: support, develop, and train supporting team members, including Project Engineers., • Maintain close relations with subcontractors, including early notification of submittal & material delivery schedule expectations., • Monitor executed subcontracts and insurance certificates; verify contracts and insurance are in place prior to commencing work., • Coordinate with Project Scheduler to update and distribute project master schedule with input from Superintendent and project team., • Assist the project Superintendent and other team members in the resolution of all critical issues, RFI’s, etc. with a focus on quality, cost and schedule; provide documentation as necessary., • Take ownership of the closeout process: complete and implement project closeout checklist., • Manage close-out documentation (as-builts, O&Ms, warranties, test reports, etc.) for submission to Design Team and Owner., • Manage financial closeout process with subcontractors and Owner., • Punch List: Upload and distribute the punch list through Procore to subcontractors., • Assist with coordinating work completion as required and maintain an accurate log of items to be completed., • Observations and Field Reports: work with project team to conduct field walks as necessary and compile any corresponding documentation accordingly. Review Design Team field reports and work with required parties to resolve open items and drive to resolutions., • Safety: perform regular safety walks with field and safety staff and record observations. Key Skills, • Strong communication skills., • Ability to review, understand and support all change management processes., • Strong initiative and problem-solving abilities., • Ability to multi-task and self-prioritize., • Motivated and driven., • Ability to work in a team environment with a primary focus on collaboration., • Excellent written and verbal presentation skills. Required Experience • A bachelor's degree in engineering, Construction Management or Architecture preferred., • 3 - 5 years’ experience within the construction industry in project management or similar role., • OSHA 10 and OSHA-30 preferred., • Additional proficiencies may include cost management software (Timberline, Sage preferred), scheduling software (Primavera P6 preferred) and construction management software (Procore preferred).

Job Description ER Electric Corp is a well-established Union Electrical Contractor specializing in Prevailing Wage electrical projects across all Westchester County, five boroughs and the surrounding region. We are committed to delivering high-quality electrical solutions with a focus on safety, efficiency, and innovation. Overview We are seeking a dynamic and detail-oriented Electrical Project Manager to lead complex electrical infrastructure projects from inception to completion. This role offers an exciting opportunity to manage large-scale projects, coordinate multidisciplinary teams, and ensure the successful delivery of electrical systems that meet all safety and regulatory standards. The ideal candidate will bring strong leadership, technical expertise, and a passion for construction management to our growing team. Responsibilities • Lead and oversee electrical construction projects, ensuring they are completed on time, within scope, and within budget., • Develop detailed project schedules using Primavera P6 or similar project management software to coordinate construction timelines effectively., • Manage project budgets, cost estimates, and financial tracking to optimize resource allocation and profitability., • Read and interpret construction plans, blueprints, and technical specifications accurately to guide project execution., • Coordinate with clients, contractors, suppliers, and internal teams to facilitate seamless communication and project progress., • Ensure compliance with all construction regulations, safety standards, and environmental policies throughout project lifecycle., • Monitor construction site activities daily, providing leadership to teams and managing subcontractors to uphold quality standards., • Utilize construction management software such as ProCore, Bluebeam, HeavyBid, Civil 3D, or Microsoft Office tools for documentation, reporting, and communication., • Oversee project scheduling efforts to align with contractual deadlines while managing potential delays proactively., • Conduct regular site inspections to verify adherence to plans and safety protocols; resolve issues promptly., • Manage contracts and change orders efficiently while maintaining accurate documentation for all project phases., • Foster a collaborative team environment by providing clear direction, mentorship, and performance feedback. Experience • Proven experience managing complex infrastructure or commercial electrical projects within the construction industry., • Strong background in construction estimating, cost management, and project scheduling using Primavera P6 or similar tools., • Demonstrated ability managing teams in a construction management role with excellent leadership skills., • Extensive knowledge of construction regulations, safety standards, blueprint reading, and contract administration., • Hands-on experience with construction site activities including coordination of schedules and resource planning., • Familiarity with construction regulatory compliance requirements specific to electrical systems is preferred., • Prior experience in managing budgets effectively while maintaining high-quality standards is essential., • Excellent time management skills with the ability to prioritize tasks efficiently under tight deadlines. Join us as an Electrical Project Manager if you’re ready to lead impactful projects that shape the future of infrastructure! Bring your expertise in construction management software like ProCore or Bluebeam along with your passion for delivering excellence on every job site. We’re excited to see how your leadership can energize our team!

Job Description Hudson Meridian Construction Group (HM), a leading New York-area construction management firm, is seeking an experienced MEP Project Manager to oversee the sophisticated mechanical, electrical, and plumbing systems that define our most complex construction projects. This role is designed for a construction professional who is also a technical expert, excelling at the intersection of pre-construction strategy, field execution, and stakeholder alignment. The successful candidate will be responsible for ensuring that the "technical core" of our builds meets the highest standards of efficiency, safety, and innovation. Core Responsibilities • Technical Stewardship: Lead the end-to-end management of HVAC, Electrical, Plumbing, and Fire Protection (MEP/FP) systems, ensuring seamless integration with structural and architectural designs., • Operational Excellence: Drive the coordination process to mitigate risks and resolve spatial conflicts well ahead of installation., • Financial & Contractual Oversight: Manage high-value MEP subcontracts, including detailed scope analysis, budget forecasting, and change management., • Commissioning & Quality: Oversee the rigorous testing and commissioning phases to ensure all systems perform to design intent and regulatory requirements. Professional Qualifications • Extensive Experience: A minimum of 8–10 years in MEP project management, with a proven portfolio in large-scale commercial, institutional, or healthcare sectors., • Academic Foundation: A Bachelor’s degree in Mechanical/Electrical Engineering, Construction Management, or a related technical discipline., • Strategic Mindset: Exceptional ability to lead multi-disciplinary teams and communicate complex technical challenges to non-technical stakeholders., • Industry Proficiency: Expert-level understanding of local building codes, LEED standards, and modern construction technologies. Willingness to travel to and across the construction sites. Project Manager Candidates will possess the ability to interpret architectural plans and specifications. Positions will require scheduling, purchasing, estimating, as well as management of personnel, vendors, and subcontractors. Candidates must be proficient with computers and familiar with Microsoft Office & CMiC. Qualified candidates must be able to effectively communicate with all levels of the organization. Position is available immediately. \nCompany Description Hudson Meridian Construction Group is one of the leading construction services firms in the Northeast, offering a unique blend of expertise to private and public sector clients. Our team delivers tailored services as Construction Managers, Program Managers, and General Contractors, bringing a commitment to excellence, collaboration, and client-focused solutions on every project. Hudson Meridian Construction Group is one of the leading construction services firms in the Northeast, offering a unique blend of expertise to private and public sector clients. Our team delivers tailored services as Construction Managers, Program Managers, and General Contractors, bringing a commitment to excellence, collaboration, and client-focused solutions on every project.

Job Description POSITION SUMMARY The Senior Construction Project Manager is responsible for the overall planning, execution, financial performance, and successful completion of assigned construction projects from preconstruction through closeout. This role serves as the primary point of accountability for project outcomes — schedule, budget, quality, and safety — while managing owner, architect, subcontractor, and internal team relationships. The ideal candidate brings deep field and commercial acumen, sound judgment under pressure, and the ability to mentor project staff while directly owning project results. KEY RESPONSIBILITIES • Lead all phases of project management for one or more construction projects, including preconstruction planning, scheduling, procurement, execution, and closeout., • Own project financials, including budgets, cost forecasting, monthly cost-to-complete reporting, and profitability tracking., • Review, negotiate, and administer prime contracts and subcontracts, including scope, insurance requirements, and change order pricing., • Develop and maintain project schedules in coordination with superintendents; proactively identify and resolve schedule risks., • Prepare, review, and negotiate change orders, RFIs, submittals, and other contract administration documents., • Manage the buyout process, including scope review, subcontractor qualification, and award recommendations., • Serve as primary client-facing contact; run owner/architect/contractor (OAC) meetings and maintain strong client relationships., • Coordinate closely with site superintendents to align field execution with contractual and schedule requirements., • Ensure compliance with safety programs, quality standards, and all applicable codes, permits, and regulatory requirements., • Manage project closeout, including punch list completion, warranty documentation, and final billing/lien releases., • Mentor and provide direction to project engineers, assistant project managers, and other project team members., • Identify risks proactively and develop mitigation strategies in partnership with senior leadership. QUALIFICATIONS • Bachelor's degree in Construction Management, Civil Engineering, Architecture, or related field, or equivalent industry experience., • 8+ years of progressive construction project management experience, including experience managing projects of significant scope and complexity., • Demonstrated experience with AIA contract documents (e.g., A101, A102, A104, A201, A401 families) and standard construction contract administration., • Strong working knowledge of project cost control, GL/cost coding, and financial reporting., • Proficiency with construction management software (e.g., Procore, Bluebeam Revu, Microsoft Project) and Microsoft Office / Excel., • Excellent negotiation, written, and verbal communication skills., • OSHA 30-Hour certification preferred, or willingness to obtain within 90 days of hire., • Valid driver's license and ability to travel to job sites as required. PREFERRED QUALIFICATIONS • Experience in [ground-up commercial / renovation / institutional — tailor to APC's typical project types]., • Prior supervisory experience managing project engineers or assistant project managers. PHYSICAL REQUIREMENTS & WORK ENVIRONMENT Work is performed both in an office setting and on active construction sites. Regular site visits require the ability to walk uneven terrain, climb stairs and ladders, and wear required personal protective equipment (PPE). Occasional lifting of up to 25 lbs. may be required. COMPENSATION & BENEFITS A. Pappajohn Company offers a competitive salary commensurate with experience, along with a comprehensive benefits package including health, dental, and life insurance, retirement plan participation, paid time off, and opportunities for professional development. \nCompany Description Mid size construction management firm located in Fairfield County. Mid size construction management firm located in Fairfield County.

Job Description Acadia (NYSE:AKR), headquartered in Rye, New York, Acadia Realty Trust (NYSE:AKR) is an equity real estate investment trust focused on delivering long-term, profitable growth via its dual – core and investment management – platforms. Our energized team is accomplishing this goal by building a best-in-class, location-driven core real estate portfolio with meaningful concentrations of assets in the nation’s most dynamic urban and street-retail corridors, including those in New York, Chicago, Los Angeles, San Francisco, Washington DC, Dallas, and Boston. At the same time, we manage opportunistic and value-add investments through our investment management platform. Acadia is seeking an experienced Regional Property Manager to oversee a growing portfolio of mixed-use retail in the NYC urban environment to join its team. The ideal candidate brings deep, hands-on familiarity with the complexities of the NYC real estate environment, with demonstrated experience managing a portfolio of 15 or more assets simultaneously. The successful candidate must have a minimum of 10 years’ experience with commercial real estate management with an emphasis on NYC condominium management, retail stores and urban shopping centers. The candidate must be a driven self-starter that can operate independently. The candidate must be a creative problem solver with the ability to make educated decisions and act swiftly to resolve issues in a fast-paced environment. A thorough understanding of NYC-specific regulatory requirements, market dynamics, tenant relationships, and operational challenges is essential. This position is based at the company’s Rye, NY corporate office but will require travel into NYC and potentially other tri-state regions to manage Acadia owned properties. Responsibilities include: Operations & Maintenance • Oversee day-to-day property operations across a mixed-use portfolio of street retail and other assets, including properties within NYC co-op and condo buildings., • Schedule and manage all vendors/contractors for routine, preventative, and emergency maintenance., • Conduct regular property inspections (exteriors, roofs, parking, mechanical rooms, tenant and vacant spaces) and take corrective action on deficiencies., • Ensure Life Safety Systems comply with all applicable local, state, and federal codes; actively monitor and remediate violations and NYC Local Law requirements., • Respond to property emergencies including after-hours.Stakeholder & Liaison Management, • Serve as primary liaison with retail tenants, co-op/condo boards, residents, managing agents, and their professionals on all operational and construction matters., • Represent ownership at co-op and condo board meetings; cultivate relationships with BIDs, local agencies (NYPD, FDNY, MTA), and other third parties., • Coordinate with internal teams — leasing, legal, construction, tenant coordination, asset management, finance, and risk management.Financial Management, • Develop and manage operating and capital budgets for assigned properties, including at the co-op/condo level., • Review and approve invoices; prepare variance reports, accruals, and reclasses.Construction & Tenant Coordination, • Oversee vanilla box and tenant construction projects; review tenant plans and manage the co-op/condo alteration approval process in coordination with the Tenant Coordination and Construction teams., • Coordinate landlord capital and common area improvement projects with the internal Construction Department and outside stakeholders. Qualifications: • Bachelor’s degree required., • 10+ years of commercial real estate management experience, with a focus on NYC retail portfolio management and NYC co-op/condo properties., • Deep knowledge of NYC co-op/condo operations: governing documents, board dynamics, managing agent relationships, financial statements, and alteration processes., • Familiarity with NYC regulatory compliance (DOB, FDNY, LPC) and compliance software., • Experience managing onsite construction and capital improvement projects, including façade, roofing, paving, HVAC, and storefront work., • Ability to read construction plans, leases, and governing documents; proficiency in budget analysis and financial reporting., • Working knowledge of building systems (HVAC, electrical, plumbing, fire/sprinkler)., • Strong leadership, communication, and organizational skills; excellent time management and analytical judgment., • Proficient in Microsoft Office Suite;, • Valid driver’s license with reliable transportation. The base salary compensation range for this role reflects the wide range of factors that are considered in making compensation decisions, including but not limited to, skill sets; experience and training; licensure and certifications; and other business and organizational needs. Compensation decisions are dependent on the facts and circumstances of each individual. A reasonable estimate of the current base salary range for this position is $110,000 - to $140,000. Employees may also be eligible to participate in an annual discretionary bonus program, subject to the rules governing the program, whereby an award, if any, depends on various factors, including, without limitation, individual and organizational performance. Acadia Realty is an Equal Opportunity Employer - Veteran/Disability

Ready to help lead the growth of a thriving water and wastewater practice in New York? \n \n Water/Wastewater Project Manager — Municipal Water Infrastructure Creighton Manning, a GAI Consultants Company · Albany, Poughkeepsie, Syracuse, or White Plains, NY · Full-time $55–$78/hour, based on location and experience · Sign-on bonus! \n \n Help build a growing water practice in New York. Creighton Manning is hiring an experienced Water/Wastewater Project Manager to lead municipal infrastructure projects and expand our New York Water Division. You'll own client relationships, pursue new work, and become the person clients, contractors and partners call first. You'll also have the backing of GAI's experienced water professionals. \n \n What You Will Do You'll lead projects from planning through start-up. Your work will cover collection, conveyance and distribution systems, pump stations, storage and treatment facilities, and rehabilitation of existing assets. \n\n • Direct multidiscipline teams and coordinate staff workload across projects.\n, • Manage scope, schedule, budget, QA/QC, safety and profitability.\n, • Oversee schematic through final design, specifications, permitting, contract documents, and bid- and construction-phase services.\n, • Lead flow projections, hydraulic modeling, master planning, alternatives analysis, cost estimating and equipment selection.\n, • Hire, mentor and develop junior engineers.\n, • Find opportunities, lead proposals and present at client interviews.\n\n \n What We Are Looking For \n\n • 10+ years of municipal water/wastewater experience in planning, modeling, conveyance and distribution design (including pipelines in public rights-of-way), treatment design, or construction services.\n, • 2+ years as a Project Manager with a track record of delivering on time and on budget.\n, • Strong technical writing, communication and leadership skills.\n, • A self-starter who enjoys winning new work.\n, • Proficiency in Microsoft Office, Microsoft Project, AutoCAD/Civil 3D, ArcGIS and hydraulic modeling software.\n\n \n Preferred Experience \n\n • 3+ years as engineer of record on water and/or wastewater projects.\n, • Trenchless pipeline design, permitting and construction.\n, • Condition assessments of facilities and pipelines, including fieldwork and data management.\n, • Projects that span more than one market.\n, • An established client network in Upstate New York.\n\n \n Who Tends to Succeed Here This role fits engineers who have moved beyond design production into project and client leadership. Many come from consulting firms with titles like senior project engineer, water resources engineer, wastewater engineer or utility engineer. They are comfortable solving complex problems across specialty areas. \n \n About Creighton Manning Creighton Manning Engineering and Surveying serves communities across New York and is part of GAI Consultants, a multidisciplinary infrastructure firm. Our water team provides planning, design and construction services for municipal clients. \n Ready to make an impact on New York's water infrastructure? Apply today or reach out for a confidential conversation. \n \n Per-Office Pay Ranges Hourly Range \n Albany \n $55 – $68 \n Syracuse \n $55 – $68 \n Poughkeepsie \n $59 – $73 \n White Plains (Westchester) \n $63 – $78 \n \n #CreightonManning

This is a remote position supporting a distributed, multi-state field workforce, working closely with the Director of Safety Operations and the Manager of EHS team. Experience in construction, telecommunications, utility, or other field-based industries. The anticipated base salary range for this re

Position at The Port Authority of NY & NJ.The Assistant Manager of Aeronautical Services plays a key role in ensuring the safety, efficiency, and regulatory compliance of.This position supports the Airport Operations Department by helping to manage FAA Part 139 compliance, coordinate construction ac

Job Description Job Title: Field Operations Intern Employment Type: Intern Division: Field Operations Department: Field Operations Work Schedule: Full-time/40-hours - In Person Salary Range: $23 - $28/hour The Field Operations Intern supports Superintendents and Project Managers by assisting with safety program administration, quantity tracking, schedule analysis, and job site documentation. This role offers hands-on experience in field coordination, schedule management, and construction quality within a dynamic construction environment. Responsibilities / Essential Functions • Support the administration of the project safety program to ensure a safe and compliant work environment., • Provide technical assistance by interpreting contract drawings, submittals, and project documentation., • Assist the assistant superintendent, superintendent, and project manager with daily and weekly activities, including preparing daily reports, conducting safety walks, compiling quantity reports, and updating project schedules., • Develop a clear understanding of the overall project schedule, including critical path analysis., • Review and contribute to the short-term planning process to ensure project milestones are met., • Participate in the quality assurance program by attending meetings, performing site inspections, and verifying materials for compliance with project specifications., • Coordinate subcontractor activities to support adherence to project timelines and safety requirements., • Maintain project documentation such as daily logs, RFIs, and submittal tracking to support effective communication and record-keeping., • Monitor onsite material deliveries and inventory to facilitate uninterrupted project progress., • Participate in project team meetings, communicating updates, challenges, and potential solutions., • Observe and report site conditions that could impact schedule, cost, or safety., • Utilize construction management software and tools to accurately track and update project information. Key Skills • Strong written and verbal communication skills to clearly convey information and coordinate with team members, clients, and subcontractors., • Demonstrated interest in construction management and the construction industry., • Proactive problem-solving abilities with an analytical mindset and excellent attention to detail for tracking schedules, quantities, and quality inspections., • Effective time management and prioritization skills to handle multiple tasks and meet deadlines in a fast-paced environment., • Strong organizational skills to manage project documentation and communications., • Ability to work independently and collaboratively within team environments., • Adaptable and eager to learn, with a team-oriented approach to support multiple stakeholders and address site challenges proactively. Required Experience • Currently pursuing a Bachelor’s degree in Construction Management, Engineering, or related field; preference for Civil Engineering or construction-focused programs., • Basic knowledge of construction site safety standards, practices, and protocols., • Proficient in Microsoft Office Suite (Excel, Word, Outlook) with aptitude for learning construction management software., • Ability to read and interpret construction drawings, submittals, and technical documents., • Strong organizational skills for managing documentation and reporting., • Basic understanding of construction scheduling, including critical path method (CPM) concepts.

Job Description An established New Jersey-based commercial general contractor is seeking an experienced Project Manager / Superintendent to lead an upcoming commercial construction project in Manhasset, Long Island. This is a project-specific contract position for a strong local construction professional who can combine hands-on field leadership with key project-management responsibilities. The selected candidate will serve as the contractor's primary on-site representative and take ownership of daily construction activities while coordinating closely with company leadership. This is not a desk-based Project Manager position. We are seeking someone who can independently drive the field, manage subcontractors and schedule, solve problems as they arise, and maintain the documentation and coordination necessary to keep the project moving. Key Responsibilities • Serve as the primary day-to-day contractor representative on site., • Manage and coordinate subcontractors for schedule, manpower, sequencing, quality, scope compliance and safety., • Maintain the project schedule and prepare detailed two-week look-ahead schedules., • Proactively identify constructability issues, scope conflicts, missing information and sequencing risks before they impact the project., • Coordinate RFIs, submittals, inspections, deliveries and other project documentation., • Maintain accurate daily reports, progress photographs and project records through Procore., • Participate in Owner/Architect/Contractor and project coordination meetings as required., • Review drawings, specifications, bulletins, RFIs, approved submittals and other current construction documents., • Maintain quality control and drive subcontractor, architect and owner punch-list completion., • Coordinate municipal and third-party inspections and project closeout through final approvals and Certificate of Occupancy., • Maintain a clean, organized and safe project site and enforce applicable OSHA and project safety requirements., • Communicate schedule concerns, cost exposure, changes and project risks promptly to company leadership., • Coordinate delivery of materials and equipment., • Monitor field activities for work outside the contracted scope and immediately notify company project leadership of potential scope changes before additional work proceeds., • Coordinate shutdowns, access, deliveries, staging and site logistics., • Assist with project closeout, including punch-list completion, final inspections, testing, owner/architect walkthroughs and required field closeout items. Qualifications • 7+ years of commercial construction experience preferred, with demonstrated experience independently running projects from mobilization through closeout., • Strong field leadership and subcontractor-management skills., • Working knowledge of commercial interiors, building systems and trade coordination., • Ability to read and interpret architectural, MEP and other construction documents., • Strong scheduling, sequencing, documentation and problem-solving abilities., • Comfortable handling both field operations and day-to-day project-management functions., • Strong Procore experience preferred., • OSHA 30 required., • Daycare/educational construction experience preferred., • Long Island construction experience and familiarity with local subcontractors, inspectors and construction practices strongly preferred., • Must be able to maintain reliable full-time daily presence at the project site in Manhasset. Compensation & Engagement $3,250–$3,750 per week, commensurate with experience and demonstrated ability to manage both field operations and project coordination. This is a project-based contract position through project completion. Weekly compensation is intended to include normal local vehicle and travel expenses. Full-time on-site presence in Manhasset is required. This is a confidential search. Additional information regarding the contractor and project will be provided to qualified candidates during the interview process. \nCompany Description Established commercial general contractor providing construction management and general contracting services throughout New Jersey, New York and the surrounding region. Our work includes commercial interiors, ground-up construction, renovations and specialty projects across multiple market sectors. We emphasize strong field leadership, accountability, safety, quality and proactive project management. Established commercial general contractor providing construction management and general contracting services throughout New Jersey, New York and the surrounding region. Our work includes commercial interiors, ground-up construction, renovations and specialty projects across multiple market sectors. We emphasize strong field leadership, accountability, safety, quality and proactive project management.

Job Description Title: Construction Superintendent Job Summary Infinity Contracting Services Corp is actively seeking a highly motivated Superintendent for a construction project(s) located in the five boroughs of New York City. We recognize our employees are the company’s most asset. Inspiration, diligence, and encouragement towards each other coupled with purposeful work lead to a rewarding career and we are proud to provide a platform with which our employees can attain their goals. The Superintendent’s position will be responsible to run the day-to-day operations and control short-term schedules. Coordinate and supervise all field staff, subcontractors, materials, and activities necessary to successfully complete a project of varying complexity. You will work with the Project Manager, Assistant Project Manager, and Project Engineer as a team to produce a quality product on time, within budget, complying with safety standards, and exceeding customer expectations. Responsibilities and Duties • Adhere and support the organization’s safety, observing OSHA and all state-level agency regulations (MTA, SCA, etc.), • Enforce orientation of job-specific training (scaffolding, aerial lift training, etc.) on-site, • Create and manage safety-related documents, • Facilitate external/internal inspections, • Host Toolbox talks and train new employees on safety standards, • Identify potential safety risks and protect workers against possible hazards, • Verify existing field conditions and report changes to affected parties, • Establish and enforce acceptable levels of workmanship and good practices, • Inspect materials for conformance against approved documents and specifications, • Identify subcontractors NCRs, communicate across project stakeholders and ensure compliance, • Identify and address punch-list items, • Plan and direct construction activities of the subcontractors, laborers, and other staff as assigned, • Monitor work progress to ensure adherence to construction schedule and budget, • Identify, order and manage resources required to finish company self-performed activities, • Assign daily tasks to field laborers, • Maintain relationships with customers, architects, union representatives, subcontractors, superiors, and project team, • Hire and layoff field labor, • Identify conflicts in construction progress and communicate them to the project team for resolution, • Initiate and communicate with project team RFIs, Submittals, and potential COs, • Arrange on-site rigging, equipment, and material deliveries, • Schedule subcontractors, consultants, and vendors in a critical path to ensure timely completion, • Attend meetings with Construction Manager/client, • Prepare daily reports, • Collect and submit payroll documentation Qualifications and Skills • 2+ year(s) superintendent and/or foreman experience, • 5 years of construction-related experience., • Possession of SST62, • Strong oral and written communication., • Excellent time management skills.

Job Description Summary/Objective: The Lead Superintendent oversees the full scope of the physical construction of the project. The Lead Superintendent is responsible for Safety, QA/QC, Subcontractor Management, Document Control, Schedule, Relationship Management & Project Management while representing Callahan Construction Managers throughout the full project cycle. The Project Superintendent is responsible for the supervision of the day-to-day work in the field and is expected to turn out high-quality work in the largest possible quantities for the lowest possible cost in the shortest possible time. The Lead Superintendent also plans in advance and ensures the flow of personnel and materials will be available. All Callahan employees are required to be respectful and professional in their day-to-day work and to be ethical in all practices. Essential Functions Safety: • Enforce compliance with all safety laws and regulations. Stop unsafe work and order Callahan, Inc., and Subcontractor employees away from hazards, etc. Ensure follow through of all safety recommendations of the Safety Manager, • Manage safety inspection reports, verify remediation has occurred and document, • Manage implementation and updating of NFPA 241 Plan. Notify and send all updates to Fire Department, • Manage site security daily - gates, fence line, signage, cameras, • Walk entire project daily reviewing overall compliance and document in the daily report, • Ensure that the project is prepared for OSHA inspections and take lead in any visits or inspection processes, • Notify Safety Manager of all incidents and near misses, • Hold stand downs as needed, • Coordinate with subcontractors and the Safety Manager for all JHAs and SOAP plans in advance of the work. QA/QC: • Create QA/QC management plan with Project Team, QAQC Manager and In House Architect, • Lead the project QA/QC process, ensuring all team members are participating in documentation, communication and execution of the plan, • Drive the process for all mockups and quality benchmarks, • Schedule, lead and document all area-specific preconstruction and mockup meetings, • Continuously monitor job progress on-site, checking all work to ensure compliance with Contract Documents, • Update QA/QC Manager on schedule, progress and issues, • Oversee the punch process, deficiency log, work to complete lists and final acceptance, utilizing PlanGrid, • Manage and verify MAAB, ADA, & FHA Compliance Subcontractor Management: • Ensure work is available to subcontractors to be successful, • Identify and resolve problems and conflicts, organize meetings and cooperate with team members in various roles as necessary, • Maintain good communication and relationships with the labor force and their leaders, • Initiate all Subcontractor Pre-mobilization Meetings (Exhibit S) with the subcontractor and all required parties to ensure that all requirements are understood, • Manage risk prevention requirements of site and Subcontractors by ensuring subcontracts and insurances are in place prior to mobilization, • Initiate badge program and ensure that all Subcontractor employees have undergone badge process and safety review prior to starting work, • Execute weekly subcontractor meetings, • Understand all subcontract scopes of work, identify scope gaps and oversee subcontractors to ensure compliance, • Manage and enforce daily cleanup and housekeeping; send notice to non-participating subcontractors, • Organize all logistics, delivery management and documentation of materials with project field staff, • Notify the Subcontractor and PM/APM of any delays resulting from labor, equipment or material shortages, • Give notice as required by subcontract agreement with written confirmation to a Subcontractor prior to performing any work for which a back charge will be processed Document Control: • Understand the plans, specifications, site, estimate, owner contract and qualifications, and subcontracts to the extent that the scope, magnitude, and relationship to the finished product are known Understand budget and attend all job cost meetings, • Manage Daily Reports, • Prepare and complete the Project Daily Report containing an accurate record of trade forces and activities, areas worked, deliveries, visitors, weather and any other pertinent information using Viewpoint Team, • Manage T&M Log - verify all slips for work was approved, log is fully detailed, • Manage and perform shop drawing review, • Provide daily photo documentation of project and upload to job folder, • Compile and maintain all permits, testing and inspections required for successful project completion and acceptance related to assigned area or scopes, • Create and track hot lists Schedule: • Create, manage and update the construction baseline schedule, • Create and update 3 week look ahead weekly, within the parameters of the current project schedule, • Provide input for schedule update, • Create and manage break out schedules for all areas, • Plan work in advance of actual operations to permit time for eliminating conflicts in plans, specifications or between trades and to ensure material and equipment deliveries as required, • Coordinate and oversee the scheduling of subcontractors, consultants, inspectors, and vendors., • Monitor and communicate with subcontractors to ensure that they maintain adequate forces and productivity to execute the work in accordance with the schedule requirements., • Own, track, update and notify of all schedule delays to Lead Superintendent, PM and PX Relationship Management: • Establish and maintain positive relations with Subcontractors, Owner, Architect, and Engineers, • Foster and encourage team environment, • Meet abutters, providing a brief overview of the project and providing your contact information, • Communicate effectively in a prompt and professional manner, • Schedule and walk with all non-MEP inspectors - Building Inspector, FD, Conservation, etc. Project Management: • Develop project specific, site-regulations, • Develop detailed phasing and turnover plan, • Prepare the site for union interruptions and understand actions in case of same, notify per procedure, • Manage daily activities to plan in advance for all needs of project, • Understand the plans, specifications, site, estimate and contract to the extent that the scope, magnitude and relationship to the finished product are known, • Attend weekly OAC meetings, • Provide input for and track procurement log, • Understand and track budget, • Notify the Project Manager of all required cost changes involving field conditions and receiving authorization before proceeding, • Manage all tool and equipment needs directly through NESB, • Follow the BIM Execution Plan and participate as required, • Create schedule for and provide weekend coverage of Project in conjunction with entire team Leadership • Provide clear direction and consistent feedback to your team, • Motivate and coach your team to achieve goals, • Mentor your staff and build relationships, • Delegate tasks to challenge your team and provide growth opportunities, • Engage and promote training and continuous learning for yourself and your team Development Goals Job Title: • Lead Superintendent Summary/Objective: The Lead Superintendent should be exhibiting the behaviors below when they are ready to be promoted to General Superintendent. The managers will use these goals to make personalized goals with their direct reports to help them achieve a promotion to the next position. Safety: • Finds new ways to promote safety planning with JHAs for their subcontractors, • Runs a safe job site with high inspection report numbers and can provide mentoring to other Project Superintendents QA/QC: • Minimizes punch list work on their projects with thorough QAQC throughout construction, • Utilizes the QAQC process to minimize items that get to the deficiency log by bringing 3rd parties into the process and closely monitoring the work., • Utilizes lessons learned from other projects to apply to their project through area preconstruction or mockup meetings. Supplies lessons learned to other teams in similar conditions., • Understands big picture of market volatility and strategizes for material and equipment management Subcontractor Management: • Plans for work with subcontractors and other projects throughout the company to ensure appropriate manpower is planned, • Identifies all relevant and appropriate content is included in Exhibit S. The ability to modify the meeting agenda as needed for a trade., • Coordinates with Project team ahead of mobilization to assure all compliance items are in place. Proactive in discussions with subcontractors to hit the ground running seamlessly, • Manages daily cleanup and housekeeping as a requirement for all, no exceptions, with worker safety as a priority Document Control: • Understands the big picture for daily reporting and how it relates to owner delays and insurance claims, • Sets a precedent with the entire subcontractor team regarding T&M work and holds true to that throughout construction. Utilizes relationship give and take to minimize costs., • Proactively brings an issue or RFI up to the General Superintendent if it is potentially impactful to other projects. Invested in current project impacts and the betterment of the company on future jobs as those relate to project issues., • Ensures the full submittal process is completed in coordination with procurement requirements Schedule: • Leads their team and site utilizing the three week look ahead schedule, • Can review a schedule for completeness and appropriate durations and logic; understands critical path., • Manages the owner delay process with the PX and communicates with other Superintendent regarding subcontractor delays that could impact other projects Relationship Management: • Leverages subcontractor, owner and design team relationships to assist with other Callahan projects., • Creates and builds strong teams., • Effective and motivational written and verbal communication with all levels Project Management: • Has experience in multiple building types, • Identifies issues in scopes/contracts/ Quals for completeness or scopes gaps prior to executed contract or work in place, • Create solutions for potential procurement issues by resequencing and problem solving, • Helps establish budgets and understands owner contract terms to facilitate ways to improve profitability Leadership: • Mentor to many and responsible for assessing, creating & delivering training

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Field Operations Department: Field Operations Reports to: General Superintendent Supervisory Duties: Yes Salary Range: $90,000 - $130,000 The Superintendent will provide overall administrative and technical management at the construction project site. This role will manage all on-site construction activities including, self-perform labor, subcontractors, and consultants. Other responsibilities will include the administration of the jobsite safety program, quality management, and overall schedule coordination and supervision. Responsibilities / Essential Functions • Administer project safety program to maintain a safe and healthy work environment., • Proficient in all 5 areas of focus on their project:, • Safety, Schedule, Cost, Quality, and creating Raving Fans with all external partners., • Develop and implement a site-specific safety plan for each project assigned., • Verify that all subcontractors have a valid subcontract and an acceptable insurance certificate prior to working on site., • Serve as the OSHA competent person for various tasks or assign others to serve as competent person., • Preplan all operations to produce innovative and efficient methods to avoid hazards. The Superintendent must correct all recognized hazards immediately., • Supervise construction effort to ensure project is constructed in accordance with the plans and specifications., • Thoroughly understand the contract (owner/subcontractor), owner requirements, contract plans, contract specifications, submittals and any change documents., • Provide technical assistance on the project, interpret contract drawings and submittals, and develop construction methods consistent with contract documents., • Work with the project team to set project goals and schedule milestones., • Coordinate all required labor, equipment, small tools, permanent materials, and supplies as needed for self-perform operations., • Create the Site-Specific Quality Plan (SSQP), manage all aspects of project quality efforts., • Complete onsite material verification as required for the project., • Manage project budget requirements:, • Assist the project manager in developing budgets and monthly cost to complete., • Manage T&M process, including verification of time and materials., • Track production and submit quantities weekly., • Identify changes in the field, authorize field change requests, provide all documentation required to ensure compensation for all work performed., • Assist in the Approval process for all subcontractor requisitions., • Manage the project to meet schedule requirements and milestones:, • Develop a baseline schedule with Project Services Group., • Track progress against baseline schedule and critical path dates., • Communicate schedule requirements at weekly subcontractor meetings., • Develop a short-term plan on a weekly basis that directly supports the project schedule and looks ahead a minimum of 3 weeks., • Coordinate and lead the daily stand up and weekly foreman meetings., • Ensure that the material delivery log is updated and accurate., • Interface with client representatives, A-E representatives, other contractors, and various building officials in a professional manner., • Participate in business development. Create Raving Fans on current projects. Utilize contacts to initiate leads for future projects., • Participate in quarterly superintendent and safety meetings, as well as periodic training sessions., • Supervise assigned foremen, assistant superintendents, and project engineers.Key Skills, • Strong communication skills., • Strong initiative and problem-solving abilities., • Ability to multi-task and self-prioritize., • Motivated and driven., • Ability to work in a team environment with a primary focus on collaboration., • Ability to work with and manage multiple people. Required Experience • Bachelor’s degree in construction management with at least 5 years of experience in the construction field or any related field., • Understands building plans and specs., • CSL preferred., • OSHA 10 Certification required; OSHA 30 Certification preferred., • Thorough knowledge of Corporate/Industry Safety standards., • Working knowledge of CPM schedule., • Working knowledge of cost report and labor production report., • Thorough knowledge of corporate quality program., • Thorough knowledge of subcontract language., • Basic computer knowledge.

Job Description Position: Superintendent Reports to: Lead Superintendent Who We Are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. The Superintendent 1 will serve as a vital team member managing specific areas of the Project in conjunction with the Lead Superintendent on the full scope of the physical construction of the project. The Superintendent 1 is responsible for Safety, QA/QC, Subcontractor Management, Document Control, Schedule, Relationship Management & Project Management while representing Callahan Construction Managers throughout the full project cycle. The Superintendent directs the day-to-day work of Callahan, Inc. tradesmen and the Subcontractors to turn out high quality work, within budget and on time. The Superintendent also plans in advance and ensures the flow of personnel and materials will be available. All Callahan employees are required to be respectful and professional in their day-to-day work and to be ethical in all practices. Essential Functions Safety: • Enforce compliance with all safety laws and regulations. Stop unsafe work and order Callahan, Inc., and Subcontractor employees away from hazards, etc. Ensure follow through of all safety recommendations of the Safety Manager, • Manage safety inspection reports, verify remediation has occurred and document, • Manage NFPA 241 Compliance, • Manage site security daily - gates, fence line, signage, cameras, • Walk entire project daily reviewing overall compliance and document in the daily report, • Notify Safety Manager of all incidents and near misses, • Track subcontractor tool box talks, • Hold stand downs as needed, • Coordinate with subcontractors and the Safety Manager for all JHAs and SOAP plans in advance of the work. QA/QC: • Assist in creating the project-specific QA/QC management plan, • Drive the process for all mockups and quality benchmarks, • Schedule, lead and document all area-specific preconstruction and mockup meetings, • Schedule and record 3rd party testing and inspections, • Manage deficiency logs including distribution of A/E and 3rd party reports, assignment of trades and documentation of item close out, • Perform and manage work to complete lists, punch lists and final acceptance in PlanGrid, • Update QA/QC manager or schedule, progress and issues, • Understand and verify MAAB, ADA, & FHA Compliance, • Manage QA/QC process and reporting requirements with staff, • Verify Subcontractor layout to ensure compliance with established line and grade, rough openings and other important dimensions and elevations, • Verify & Execute:, • Dimensional verification, • Work in place is accurate to design and approved shop drawings, • First material Inspection log Subcontractor Management: • Run Subcontractor Pre-mobilization Meetings (Exhibit S) for their area, • Manage risk prevention requirements of site and Subcontractors by ensuring subcontracts and insurances are in place prior to mobilization, • Manage badge program and ensure that all Subcontractor employees have undergone badge process and safety review prior to starting work, • Ensure work is available to subcontractors to be successful, • Identify, resolve problems and conflicts, organize meetings and cooperate with team members in various roles as necessary, • Maintain good communication and relationships with the labor force and their leaders, • Run weekly subcontractor meetings, • Manage delivery schedule, record deliveries and coordinate storage and work areas, • Understand all subcontract scopes of work and oversee subcontractors to ensure compliance, • Manage and enforce daily cleanup and housekeeping, notifying Lead Superintendent of any non-participating subcontractors, • Notify the Lead Super of any delays resulting from labor, equipment or material shortages, • Give notice as required by subcontract agreement with written confirmation to a Subcontractor prior to performing any work for which a back charge will be processed Document Control: • Prepare and complete the Project Daily Report containing an accurate record of trade forces and activities, areas worked, deliveries, visitors, weather and any other pertinent information using Procore, • Manage T&M Log - verify all slips for work was approved, log is fully detailed, track labor usage, • Manage and perform shop drawing review, • Create clear and concise RFIs and offer solutions whenever possible, • Provide daily photo documentation of project and upload to job folder, • Compile and maintain all permits, testing, and inspections required for successful project completion and acceptance related to assigned area or scopes, • Create and track hot lists Schedule: • Create and update 3 week look ahead every week, • Manage break out schedules for all areas, • Complete the update form ahead of all schedule update meetings, • Review schedule updates with the Scheduler and Project Manager to address issues and work toward resolution and improvements, • Monitor and communicate with subcontractors to ensure that they maintain adequate forces and productivity to execute the work in accordance with the schedule requirements., • Own, track, update and notify of all schedule delays to Lead Superintendent, PM and PX Relationship Management: • Establish and maintain positive relations with Subcontractors, Owner, Architect, and Engineers, • Foster and encourage team environment, • Meet abutters, providing a brief overview of the project and providing your contact information, • Communicate effectively in a prompt and professional manner, • Schedule and walk with all non-MEP inspectors - Building Inspector, FD, Conservation, etc. Project Management: • Manage daily activities to plan, in advance for all the needs of project, • Understand the plans, specifications, site, estimate to the extent that the scope, magnitude, and relationship to the finished product are known, • Provide input for tracking procurement log, • Attend weekly OAC meetings, • Understand and track budget, • Notify the Lead Super / Project Manager of all required cost changes involving field conditions and receiving authorization before proceeding, • Manage all tool and equipment needs directly through NESB, • Follow the BIM Execution Plan and participate as required, • Provide weekend coverage of project in conjunction with entire team Leadership • Provide clear direction and consistent feedback to team, • Motivate and coach team to achieve goals, • Mentor staff and build relationships, • Delegate tasks to challenge team and provide growth opportunities, • Engage and promote training and continuous learning for team All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color, religion, sex, sexual orientation, gender identity, national origin, or on an applicant's status as a protected veteran or as an individual with a disability.

Job Description We are hiring! ACS System Associates, Inc. established in 1983 is one of ENR top rated MBE privately held HVAC Commercial Companies. ACS is renowned for projects such as World Trade Center, Brooklyn Navy Yard, Stony Brook Hospitals, and a wide variety of both private and public work projects in the Greater New York area including Westchester, New York City, and Long Island. The diverse portfolio includes retail, office, industrial, hotel, schools, and hospital projects. We have an internal division complete with engineers, architects, draftsmen, project managers, and supervisors. These specialists work with clients such as Tishman, Turner, and Lend Lease to make sure each project is done effectively, on time, and within budget. We offer a lucrative benefits package to our employees that include Medical, Dental, Vision, 401K, PTO, Life Insurance, Education reimbursement to name a few. Headquartered in Long Island, NY with additional offices in Westchester County. We are seeking experienced Site Supervisors with HVAC knowledge as we expand. Key Duties & Responsibilities: • Managing and maintaining the project schedule from start to finish., • Working with the Project Manager, General Contractor, other trades, and suppliers to resolve issues/questions in a timely and cost-effective manner., • Adhering to plans specifications., • Reviewing all work for quality and accuracy., • Coordinating workers to meet the project schedule., • Reviewing and managing supplier deliveries., • Ensuring the cleanliness of site, • Ensuring that all site activities comply with safety regulations and procedures., • The coordination of subcontractors (as needed), • Engaging in hands-on work to keep the project on schedule., • Reporting and tracking on-site changes and progress, • Embracing teamwork with all trades to complete the project., • Must have current SST 62, • Must use own car Requirements: • 5 years of superintendent/field manager experience in the HVAC or General Contracting, • Proven track record of successfully completing projects on time and on budget., • Valid OSHA 30-hour and NYC DOB SST62 certification, • Proficiency with construction management software, • Must either live in Nassau, Western Suffolk, Within 5 Boroughs of NYC or Westchester Primary Location: United States-New York-Hicksville Other Locations: United States-New York-Westbury Other Locations: United States-New York-Mount Vernon Applicants must be authorized to work in the U.S. All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, national origin, disability, protected veteran status, or any other characteristic protected by law. • Job Type: Full-time\nCompany Description, • With a $ 250 Million Bonding Line, ACS is a Major Player in Government and Private Construction Contracts., • Job Stability to our Team Members is ensured by Dozens of Ongoing Contracts at all times in NYC 5 Boros ,L.I, Ct and the vicinity., • We are looking forward to expand our Team to take on challenging assignments as we embark on Major Expansion., • Our Associates are our Most Valued and Greatest Corporate Asset .We seek to maximize this Asset by assisting all our Associates ,in every which way, in realizing their Highest Professional Potential. Additionally ACS regularly works on HUD Section 3 Projects with hiring priorities for low-income persons., • With a $ 250 Million Bonding Line, ACS is a Major Player in Government and Private Construction Contracts.\n\n Job Stability to our Team Members is ensured by Dozens of Ongoing Contracts at all times in NYC 5 Boros ,L.I, Ct and the vicinity.\n\n We are looking forward to expand our Team to take on challenging assignments as we embark on Major Expansion. \n\n* Our Associates are our Most Valued and Greatest Corporate Asset .We seek to maximize this Asset by assisting all our Associates ,in every which way, in realizing their Highest Professional Potential. Additionally ACS regularly works on HUD Section 3 Projects with hiring priorities for low-income persons.

Verde Electric Corp is seeking an experienced Fleet Manager to oversee and manage a commercial fleet of 150+ trucks and vehicles. This is a hands-on management position responsible for ensuring the fleet is safe, reliable, compliant, properly maintained, and available to support the company's daily operations. The Fleet Manager will oversee vehicle maintenance and repairs, preventive maintenance programs, regulatory compliance, fuel management, fleet-related purchasing, vendor relationships, vehicle replacement, and fleet operating costs. The ideal candidate will have significant experience managing a large commercial fleet and be comfortable working with drivers, mechanics, operations management, outside vendors, and senior leadership. Fleet Operations · Manage the company's fleet of 150+ trucks and vehicles. · Maintain accurate records for all vehicles, including maintenance, inspections, registrations, titles, mileage, and repair history. · Monitor vehicle utilization, availability, downtime, and operating costs. · Establish procedures to maximize fleet reliability and minimize vehicle downtime. · Coordinate vehicle assignments, replacements, transfers, and disposal. Maintenance & Repairs · Develop and manage a comprehensive preventive maintenance program. · Schedule routine service, inspections, repairs, and emergency maintenance. · Monitor vehicle condition and identify issues before they become major repairs. · Manage relationships with dealerships, repair facilities, mobile mechanics, parts suppliers, and other vendors. · Review and approve repair estimates and invoices. · Negotiate pricing and service agreements with outside vendors. · Track maintenance costs by vehicle and identify opportunities to reduce expenses. Safety & Regulatory Compliance · Ensure all vehicles are properly inspected, registered, insured, and maintained. · Manage initial vehicle registrations and timely registration renewals for all fleet vehicles. · Maintain and update insurance coverage and documentation for all company vehicles and equipment. · Prepare and submit the annual diesel emissions inventory report. · Maintain compliance with applicable DOT, FMCSA, OSHA, state, and local requirements, as applicable to the company's operations. · Maintain required vehicle and driver documentation. · Coordinate DOT inspections and ensure deficiencies are corrected promptly. · Work closely with the company's safety department to address fleet-related safety issues. · Monitor accident and vehicle damage reports and coordinate repairs and claims. Financial & Administrative Management · Develop and manage the annual fleet maintenance and operating budget. · Track fuel, maintenance, parts, repairs, and other fleet-related expenses. · Manage quarterly Highway Use Tax (HUT) filings and payments. · Manage annual Heavy Highway Vehicle Use Tax filings and renewals. · Maintain and administer the fleet fuel card program, including card issuance, updates, account maintenance, and usage monitoring. · Manage International Fuel Tax Agreement (IFTA) reporting and filings, including maintenance of fuel purchase and mileage records. · Identify cost-saving opportunities without compromising safety or reliability. · Review vendor invoices for accuracy and proper authorization. · Provide regular fleet performance and expense reports to management. Fleet Acquisition & Replacement · Assist management in determining vehicle replacement schedules. · Research truck specifications and recommend appropriate vehicles for company operations. · Obtain and compare pricing from dealers and manufacturers. · Coordinate the acquisition, upfitting, delivery, registration, and deployment of new vehicles. · Manage the sale or disposal of retired vehicles. Qualifications · 5+ years of fleet management experience, preferably managing 100+ commercial vehicles. · Experience with trucks and commercial vehicles strongly preferred. · Knowledge of DOT/FMCSA regulations and commercial vehicle compliance. · Strong knowledge of preventive maintenance and vehicle repair. · Experience managing outside repair facilities and vendors. · Strong organizational and record-keeping skills. · Ability to manage multiple priorities in a fast-paced operating environment. · Strong communication and negotiation skills. · Proficiency with fleet management software and Microsoft Office. · Valid driver's license with a clean driving record. Preferred Experience · Experience managing a 150+ vehicle construction, electrical, utility, transportation, or similar commercial fleet. · Experience with pickup trucks, service trucks, vans, trailers, and heavy-duty vehicles. · Experience with fleet telematics/GPS and fuel-management systems. · Experience managing vehicle acquisition and replacement programs. · Experience managing fleet budgets and reducing operating costs. What We Offer · Competitive salary based on experience. · Performance-based compensation. · Company benefits package. · Paid time off and holidays. · [401(k) / Health Insurance / Other Benefits] · Opportunity to play a key role in managing and improving a large company fleet. How to Apply Please submit your resume to nestatico@verdeelectric.com rdileonardo@verdeelectric.com

The expected salary range for this position is $140,000 - $180,000 depending on experience*NO STAFFING AGENCY CANDIDATES WILL BE CONSIDERED FOR THIS POSITIONApplicants must be eligible to work in the United States without visa sponsorship now or in the future***Tutor Perini Corporation is seeking a VDC Manager for our New Rochelle, NY corporate office.About Tutor Perini CorporationExtraordinary Projects, Exceptional PerformanceThe world relies on infrastructure — to ensure public safety, maintain a quality of life and support a healthy economy. For more than a century, Tutor Perini Corporation’s family of civil construction companies has supported the development and maintenance of infrastructure across our great nation.We construct and rehabilitate highways, bridges, tunnels, mass-transit systems, and water management and wastewater treatment facilities. In short, we help our clients make “public works” work. Our corporate integrity, financial strength and outstanding record of performance makes us an attractive partner on large, sophisticated infrastructure projects.From coast to coast, notable projects include The Purple Line (D Line) Extensions in Los Angeles, SR 99 Viaduct replacement tunnel in Seattle, East Side Access projects and the Hudson Yards Platform in New York, Central Subway Third Street Light Rail in San Francisco, and multiple airport expansions and bridge projects. At Tutor Perini Civil you will have the opportunity to work on a variety of large, high-profile, projects that impact your community.Extraordinary Projects need Exceptional TalentPosition OverviewWe are seeking an experienced Virtual Design & Construction (VDC) Manager to lead digital delivery on a large, complex infrastructure project with stringent technical, coordination, and security requirements. This role is responsible for overseeing all BIM/VDC activities across the project lifecycle while ensuring compliance with owner standards, construction schedules, and asset management deliverables.The VDC Manager will manage the project VDC team, including a dedicated BIM Specialist and junior VDC engineers. While this is a leadership position, it also requires a manager who is comfortable remaining closely engaged with the technical work, particularly on complex, high‑risk, or time‑sensitive efforts.Job Description:VDC & BIM LeadershipLead all Virtual Design & Construction activities in accordance with project‑specific BIM/VDC requirements, standards, and execution plans.Serve as the primary point of contact for BIM/VDC coordination with the Owner and key project stakeholders.Develop, maintain, and enforce the BIM Execution Plan (BEP), ensuring consistent application across all disciplines and partners.Oversee the development and coordination of discipline models, federated models, and construction models throughout all phases of the project.Technical Oversight & ContributionMaintain a working familiarity with active models, coordination issues, and digital workflows to ensure quality and continuity.Provide direct technical support or contribution when project complexity, schedule demands, or risk warrant closer involvement.Support model federation, coordination reviews, and resolution of complex or escalated issues. Guide refinement of BIM/VDC workflows, standards, and deliverables to meet project and owner expectations.Coordination, Constructability & Digital DeliveryLead 3D coordination and clash detection processes across all disciplines and trade partners.Facilitate regular coordination meetings and ensure timely issue resolution.Oversee 4D and 5D modeling efforts supporting construction sequencing, logistics planning, progress tracking, and reporting.Ensure digital models accurately reflect construction means, methods, and verified field conditions.Construction Phase & TurnoverManage monthly and milestone BIM/VDC deliverables, including progress models, federated coordination models, and construction simulations.Ensure appropriate quality control is applied to all BIM/VDC deliverables prior to submission.Oversee development of accurate as‑built / as‑constructed models suitable for owner turnover and asset management integration. Coordinate validation activities, including integration of survey and laser scan data where required.Team Leadership & DevelopmentManage and mentor a dedicated BIM Specialist and junior VDC Engineers.Support knowledge transfer and skill development through structured tasks, reviews, and collaboration.Contribute to the growth and maturity of the organization’s VDC practices, standards, and internal capabilities.Required Qualifications:Bachelors degree in civil engineering, construction management, architectural engineering or related field from an accredited institution.5+ years of experience on large, complex construction or infrastructure projects.3+ years of experience leading BIM/VDC workflows for design and construction.Demonstrated ability to balance strategic oversight with appropriate technical engagement.Strong understanding of BIM methodologies, coordination workflows, and Level of Development (LOD) standards.Proficiency with industry‑standard tools such as Autodesk Revit, Civil 3D, Navisworks, Synchro 4D, and common data environments.Experience working in environments with strict documentation, quality control, and security requirements.Strong communication and collaboration skills.Experience on high‑security, mission‑critical, or operationally sensitive projects, such as transportation facilities, aviation, utilities, government, or other controlled infrastructure.Experience mentoring junior engineers or supporting structured development programs.Familiarity with asset management integration and digital handover requirements.Background in civil infrastructure, transportation, or heavy construction.OUR MISSIONWe build critical infrastructure that creates a better world.OUR VISIONWe strive to be the preeminent full-service civil, building, and specialty contractor by delivering innovative, transformative projects through world-class execution. We are committed to creating lasting value for our customers, upholding the highest standards of safety and integrity, generating exceptional financial results and shareholder value, and fostering a culture where our employees thrive.Equal Opportunity EmployerSummaryLocation: New Rochelle, NY Type: Full time

If you are a forward-thinking professional passionate about innovation and product strategy, we invite you to explore this exciting opportunity! Vantage Elevation is seeking a collaborative and results-driven Product Manager to join our growing team. Reporting directly to the VP, Product Management, the Product Manager owns and drives the full lifecycle of the company's product portfolio, including product strategy, roadmaps, product launches, enhancements, value engineering initiatives, and product retirement. This role works cross-functionally to align business objectives, support innovation, and strengthen the company's competitive position in the market. The Product Manager collaborates closely with sales, marketing, technical support, and customers to translate market insights, competitive analysis, and voice-of-customer feedback into product development priorities and value-driven pricing strategies. This role also plays a key part in successful product adoption by supporting frontline teams with product knowledge, release deployment, and early customer implementation activities. Vantage Elevation, LLC is an independent, industry-leading manufacturer of elevator components and systems with a long history of innovation and reliability. Founded in 1899, Vantage employs over 1,000 people across manufacturing sites and offices in the United States, Canada, and the United Kingdom. Through its family of brands, GAL Manufacturing, GAL Canada, Hollister-Whitney, Elevator Controls, Courion, Bore-Max, Thames Valley Controls, and Vertical Dimensions, Vantage supports nearly every electro-mechanical device used in modern elevators. Vantage's mission is to safely connect people and communities by providing reliable elevator solutions. We support our teams, work closely with our customers, and hold ourselves accountable for quality, safety, and integrity in everything we do. Product Strategy: Collaborate to define/execute the product strategy & roadmap, aligned with Vantage strategic objectives Collaborate with functional peers to drive company-wide strategies Communicates with authorities, business and professional associations and other related influencers to influence standards and codes, and to promote product solutions Actively supports the execution of Vantage transformation initiatives and leads Vantage transformation initiatives as assigned. Product Lifecycle Management: Oversee the entire lifecycle of the product from conception through release and enhancements Implement best practices in product management and continuous improvement processes Ensure products meet market needs and customer satisfaction goals Market and Customer Insight: Lead market research, competitive analysis, and customer engagement initiatives to inform product strategies Participates in sales target identification and in defining new target markets and customers Utilize analytics and data-driven decisions to improve product offerings. Participates in pricing strategies and models based on market dynamics and company objectives working in concert with the commercial team, business units, and finance. Responsible for product CPQ modeling and will work in concert with the product data team to optimize product modeling and ensure accurate product costing and pricing. Responsible for the development of our parts offering within the business units, and importantly within our regional service centers. Cross-Functional Collaboration: Work with R&D, marketing, sales, customer support teams, and operations to ensure product success Foster a collaborative culture and process between product teams and other departments Coordinate go-to-market strategies and ensure successful product launches Supports Sales Development Managers in achieving targets and analyzing and maintaining offering, product and pricing data, sales and tendering tools and pricing guidelines Transfers information and knowledge of his/her offering range front lines Financial and Operational Oversight: Provide executive-level reporting on product performance, strategic milestones, and targets Oversee the development and management of key performance indicators (KPIs) for the product management function Customer relationship management: Works in concert with sales and marketing to create support material for front lines in defining, specifying and communicating customer value of product offerings in concert with marketing. Works in concert with sales and marketing to identify and articulate benefits and advantages of the Vantage product offering in customer materials Acts as company liaison for all product related communications related to quality issues or topics, and key product support topics Participates in customer meetings and events Performance Measures: Business metrics: Orders (Volume & Monetary Value), Orders Margin, Sales, EBITDA, EBITDA Margin, NPI, Vitality Index Development of market share Development, implementation and utilization of Vantage solutions, processes, and tools Contribution to winning orders working together with Salespersons and Account Managers Quantity and quality of feedback to product life cycle management Requirements Bachelor's degree in a commercial or technical field, or related field required 5-7 years product lifecycle management experience Ability to travel (35%) Experience in Pricing strategy and leadership Experience in business performance management Elevator, construction or relevant B2B environment experience Excellent and proven analytical skills Detail oriented and operates with a high level of accuracy Strong presentation, communication, organizational skills Demonstrated ability to define, analyze and research Ability to operate in a fast-paced environment, handling & prioritizing multiple projects/tasks Advanced in Microsoft Office (Excel, PowerPoint, and Word) Ability to think creatively, highly driven and self-motivated Ability to work independently and as a part of a team Proven ability to interface with senior management and peers Benefits of Working With Us Salary for Applicants: $115,000 - $120,000 (Actual compensation will be determined based on experience, location, and in keeping with local legislation). Medical/Dental/Vision/Life Insurance HSA Employee Assistance Program (EAP) Plum Benefits and more! Vantage Elevation, LLC provides equal employment opportunities to all employees and applicants for employment and prohibits discrimination and harassment of any type without regard to race, color, religion, age, sex, national origin, disability status, genetics, protected veteran status, sexual orientation, gender identity or expression, or any other characteristic protected by federal, state, or local laws. This policy applies to all terms and conditions of employment, including recruiting, hiring, placement, promotion, termination, layoff, recall, transfer, leaves of absence, compensation, and training.

Construction Planning Supervisor Veolia in North America is the top-ranked environmental company in the United States for three consecutive years, and the country's largest private water operator and technology provider as well as hazardous waste and pollution treatment leader. It offers a full spectrum of water, waste, and energy management services, including water and wastewater treatment, commercial and hazardous waste collection and disposal, energy consulting and resource recovery. Veolia helps commercial, industrial, healthcare, higher education and municipality customers throughout North America. Headquartered in Boston, Veolia has more than 10,000 employees working at more than 350 locations across North America. The Planning Supervisor is responsible for planning, scheduling and coordinating all aspects of such work to be performed for United Water New Rochelle and United Water Westchester. Will be responsible for short and long-term planning. Administer management policies and directives; trains and evaluates staff on performance of work as it relates to the planning and scheduling functions. The role of the Maintenance Planner is to improve work force productivity and work quality by anticipating and eliminating potential delays through planning and coordination of all available resources including manpower, materials and equipment. He/she is responsible for planning, scheduling and coordinating all aspects of such work to be performed for Veolia Westchester. They will be responsible for short- and long-term planning. Administers management policies and directives; trains and evaluates staff on performance of work as it relates to the planning and scheduling functions. The planning and scheduling function is the hub from which all known maintenance activity is coordinated. It is the process of describing a job in terms of how it is to be performed and what resources will be required. S/he is the principal contact person between the Maintenance and Operations groups in relation to the planning and scheduling of daily work activities. Primary Duties/Responsibilities: • Understanding of aspects of jobs within Operations group well enough that he/she can describe what is to be accomplished and can estimate the required man-hours and resources to be allocated., • Is the principal contact and liaison person between T&D Department System Maintenance and Production, along with other supported departments., • Is responsible for long-range as well as short-range planning. Long-range planning involves the regular analysis of backlog relative to available resources. These two basic variables must be kept in balance if a proactive maintenance environment is to be established and sustained., • Short-range planning and scheduling consist of the following:, • Initial Job Screening, • Analysis of Job Requirements, • Job Research, • Detailed Job Planning, • Job Preparation, • Materials Needed/Procurement, • Job Scheduling and Coordination, • Daily Schedule Adjustment, • Responsible for the full utilization and user training associated with the current and future InFor database management systems for Westchester. This system tracks operational and financial information providing management with accurate, comprehensive and timely information regarding the status and trend of the Company operations. The collection of this information is critical in the reporting of statistical information to the NYSPSC, rate cases, monthly preparation and review of performance measures and indicators established by management as well as the capital & expense monthly accruals. Incumbent is responsible for system testing, and implementation of the integrated business systems used in decision making including within Westchester. All updates and system testing are coordinated through the incumbent, and properly designed for the business unit. Incumbent will be defined as the "subject matter expert" in field of maintenance management system, for the above and below ground facilities systems., • Weekly review of performance indicators (KPI) as they relate to schedule compliance, staff utilization, efficiencies, overtime, backlog and non-value added time. Additionally, review with dept supervisors/company Managers the next week's work schedule. Required Key Performance Indicators (K.P.I.s) to be reported weekly to dept/company manager and general manager., • Ability to prepare written technical reports and interact effectively and diplomatically with management and/or bargaining unit employees as well as regulators, consultants, municipal officials, health officers, customers, contractors, and the general public., • Knowledge of applicable health and safety regulations, practices, procedures and water quality monitoring practices, along with all other water industry standards., • Monitor and adhere to departmental operational and capital budgets., • Organize workload to comply with deadlines and priorities, work independently to complete routine department functions and prepare and handle confidential correspondence and reports for review by Management., • Clearly communicate staff's duties and responsibilities, work policies, rules and regulations., • Establish procedures for handling contingencies and emergencies, and planning for adequately staffing for emergencies and absences., • Maintains department records and files., • Participate in developing and implementing the department's operational scheduling and standard operating procedures., • Manage work in progress of private contractors to verify the quality of work as well as accuracy and completeness of work, reports and invoices submitted to Westchester. Provide assistance to the Engineering Department in the prioritization of the Capital Projects., • Provide control report and progress graph charts for regular analysis and corrective actions., • Must be able to respond to emergency calls and work extended hours as needed (The incumbent must be a member of the Westchester On Call Team and be part of the Emergency On Call Rotation., • Provide support on special projects as assigned by the Manager of Asset & Workforce Management and/or Westchester's management team., • Commitment to health, safety and protection of the environment: The incumbent supports Veolia's commitment to safety by complying with the programs regarding health, safety and protection of the environment. The incumbent demonstrates safe work practices, takes part in safety meetings, and immediately advises the supervisor of any non-conforming conditions., • Management has the right to add or change these duties of the position at any time. Work Environment: • While performing the duties of this job, the employee is occasionally exposed to outside weather conditions. Qualifications: Education/Experience/Background: • Bachelor's degree in business administration or related field is preferred or equivalent work experience., • Any combination of education, experience and training which provides the equivalent scope of knowledge, skills, and abilities necessary to perform the work., • 3-5 years related work in operations is required., • Previous supervisory experience required. Knowledge/Skills/Abilities: • Proficient computer skills (Microsoft suite, Google, Adobe, Hexagon, GIS, CC&B, HACH WIMS, Workday, etc.), • Familiarity with the "KEY" maintenance management system is preferred., • Extensive knowledge with the asset management/maintenance management (Hexagon) systems., • Requires superior interpersonal and communication skills and the ability to develop and maintain good working relationships internally (management / bargaining group) as well as externally (local, county, state agencies) etc., • Excellent management and organizational skills are also required., • Ability to prioritize and work simultaneously on several projects., • Operate effectively within a team atmosphere., • Strong analytical, statistical and data management skills., • Capable of shifting priorities frequently and effectively under pressure., • Demonstrated commitment to promoting a safe work environment., • Must be able to read complex operations and financial reports. Write detailed reports and prepare and deliver presentations. Analyze complex operational and technical challenges and resolve same. Physical Requirements: • Primary functions require sufficient physical ability and mobility to work in a field/office environment: to walk, stand, and sit for prolonged periods of time: to frequently stoop, bend, kneel, crouch, crawl, climb, reach, twist, grasp, and make repetitive hand movement in the performance of daily duties., • Ability to lift, carry, push and/or pull moderate amounts of weight., • Must be able to see clearly and hear., • Must be able to speak to give direction and converse with others. Additional Information: Pay Range: $90000 to $100000 per year. Benefits: Veolia's comprehensive benefits package includes paid time off policies, as well as health, dental, vision, life insurance, savings accounts, tuition reimbursement, paid volunteering and more. In addition, employees are also entitled to participate in an employer sponsored 401(k) plan, to save for retirement. We are an Equal Opportunity Employer! All qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, national origin, disability or protected veteran status.

TRC has long set the bar for clients who require more than just engineering, combining science with the latest technology to devise innovative solutions that stand the test of time. From pipelines to power plants, roadways to reservoirs, schoolyards to security solutions, clients look to TRC for breakthrough thinking backed by the innovative follow-through of an industry leader. TRC's professionals work with a broad range of commercial, industrial and government clients and the communities they serve. We deliver breakthrough solutions that address local needs -- so our clients can better succeed in an ever-changing world. Working at TRC means tackling interesting, meaningful projects. We pride ourselves on our collaborative spirit, entrepreneurial zeal and agile corporate structure. We recognize that the expertise of our staff is our strongest asset, so we generously reward employees for successful performance and invest in their careers through training and the development of new skills and certifications. • Ability to prepare correspondence, reports, and recommendations concerning construction issues., • Supervising, coordinating, and inspecting quality in the field to make sure it meets plans and specifications. Assisting and advising inspectors regarding project management of any major or inconsistent discrepancies, making sure documentation and records are compliant with project budget, and provide assurance to clients that the project has been constructed in accordance with the plans and following all site safety procedures in accordance with OSHA, as well as Company and project specific guidelines., • NICET IV certification or qualifying equivalent education or experience., • Must have bridge and/or highway construction experience, with NYSDOT preferred., • Familiarity with NYSDOT MURK Documentation and using AWP is preferred., • Excellent verbal and written communication skills., • Must have the ability to work independently with minimal supervision., • Night Shift, over-time and potential weekend work availability., • Must have a valid driver's license and a reliable vehicle., • Minimum of 10 years of experience with knowledge of highway, bridge, facilities and rail construction practices and procedures as required with a minimum of 5 years of direct experience with New York State Department of Transportation (NYSDOT)., • Currently possess NICET IV., • Experience in NYSDOT Site Manager payment system. Additional certs such as ACI Concrete Field-Testing Certification, Rutgers Traffic Control Coordinator, NJSAT, and NECEPT preferred., • Must have a valid driver's license and a vehicle., • Occasional irregular or extended work hours such as Night Shift /Weekend work availability. Benefits: TRC offers a competitive benefit package consisting of: • Medical, dental, vision, and disability insurance., • 401k package that includes both traditional and Roth IRA options and Company match., • Paid time off contingent upon full time or part-time status and level of seniority (ranging from 15 to 25 days per year)., • All full-time employees enjoy a minimum of 8 Paid Holidays per year., • TRC ensures that all employees, including those that work part-time, receive paid sick, family, and disability leave in accordance with the laws of their state of residence. Compensation: In accordance with local law, the below salary range is applicable for the job and location associated with this requisition. Compensation will vary based upon experience, education, skill level, geographical location, and other compensable factors. Other Compensation: Employee may be eligible for participation in the Company's annual Discretionary Bonus Program which is contingent on Company, Business Segment, and Individual performance against Key Performance Indicators which vary by year and employee. TRC is an Equal Opportunity Employer. We do not discriminate on the basis of race, color, religion, sex, sexual orientation, gender identity, national origin, age, disability, veteran status, or any other characteristic protected by applicable law. All employment decisions are made based on qualifications, merit, and business needs. We celebrate diversity and are committed to creating an inclusive environment for all employees.

Construction Operations White Plains, New York, United States Intern Please note: • Applying for positions in multiple locations will result in a longer vetting process., • The Whiting-Turner Contracting Company is an Equal Opportunity Employer, including the disabled and veterans. What It Takes Open to undergraduate students interested in gaining hands-on practical experience in the construction field. Qualified applicants will assist project teams in managing construction projects/ including all phases from bidding to final completion. • Assignments include office and job site; relocation to a remote sites may be required., • Transportation is required., • Work periods are 10-12 weeks; 40 hours/week., • Housing may be provided in certain situations. Reporting Relationship: Depending on the work assignment, interns will report to a project manager, superintendent, project engineer or field engineer. You may be assigned to the office, jobsite or mix of both. Tasks Assigned: You will be learning the engineering and technical aspects of the project both in the field and in the office. Your experience will include some or all the following: • Quantity take-off, • Layout, • Preconstruction/as-built surveys, • Shop drawing review/approval & maintenance of log, • Submittal review/approval & maintenance of log, • Request for information (RFI) review/submission & maintenance of log, • Responding to subcontractor RFIs, • Interfacing with subcontractors & suppliers, • Attending weekly progress meetings, • Assisting with coordinating the work between the owner, architect & subcontractors, • Assisting during the bid process, • Assist with reviewing construction documents & specifications, • Assisting with reviewing all document revisions & clarifications, • Assisting with maintaining field record, • Assisting with estimates/budgets/value engineering/constructability surveys Assist with writing contracts & purchase orders, • Assisting with preparing billings to owner & submitting change orders, • Assisting with approval of invoices, • Assisting with ordering & expediting materials, • Assisting with scheduling & updates, • Assisting with quality control & safety, • Assisting with settling contracts, • Assisting with permit process, • Assisting with performing costing, scheduling, estimating & project management, • Punchlist & project closeout, • Cooperating & working with field project management, • And any other duties that may be assigned Required Skills Technical Capabilities You should be familiar with the following software: Primavera, Microsoft Word, Microsoft Excel, Microsoft Access, Microsoft PowerPoint, Microsoft Outlook, Microsoft Exchange, etc. Salary Range $20.91 - $29.28

Langan provides expert land development engineering and environmental consulting services for major developers, renewable energy producers, energy companies, corporations, healthcare systems, colleges/universities, and large infrastructure programs throughout the U.S. and around the world. Our employees collaborate seamlessly among 40+ offices and gain valuable hands-on experience that fosters career growth. Langan culture is entrepreneurial from advancing innovative technical solutions, to participating in robust training and knowledge sharing, to making progressive change within the communities we live and work. Consistently ranked among the top ten "Best Firms to Work For" and Engineering News-Record's top 50 firms worldwide, Langan attracts and retains the best talent in the industry. Employees thrive at Langan, a firm that fosters an inclusive and supportive work environment for all; prioritizes wellbeing, health, and safety; encourages volunteerism and philanthropy; offers workplace flexibility, along with carbon-neutral office spaces; and empowers individuals to contribute their skills and knowledge to make impactful contributions. Job Summary Langan is seeking a Civil Project Manager to join its collaborative and expanding team in White Plains, NY, New York City, NY, Parsippany, NJ or Princeton, NJ. This person will serve a key function in leading multi-discipline professionals in site/civil project efforts, and developing colleagues and business throughout the Westchester County, Hudson Valley, and Capital Regions. In this role, you will have the opportunity to continue building upon a well-established practice with a diverse portfolio of land development projects including grid resiliency, renewable energy, commercial centers, residential developments, warehouse distribution centers, and mixed-use projects for both public and private sector clients. • Lead the planning, design and permitting of civil engineering, land development and infrastructure projects., • Coordinates and provides client communication; Civil design, SWPPP controls and inspections, and construction oversight of underground electrical ductbank., • Manage the New York State Article VII process through the application development, implementation of supporting studies, Environmental Construction and Management Plan (EM&CP) development, and Environmental Monitor oversight role., • Design and oversee site layout, grading, drainage, infrastructure, erosion and sediment control, etc. from concept through completion., • Develop new clients for the firm and maintain relationships with existing clients., • Perform and manage multiple projects and tasks within specific budgets, schedules, and deadlines. Monitors budgets, schedules, and project timelines. Minimizes write-offs by keeping projects on budget., • Report and proposal writing. Write and review draft reports, including feasibility studies, stormwater management reports, technical specifications, and utility reports., • Provide expertise in hydrologic/hydraulic analysis and design including SWPPP preparation and water quality compliance., • Work closely with office leadership to develop growth plans and ensure staff utilization., • Perform other duties as requested., • 7+ years' experience in siting, designing, permitting, and overseeing the construction of linear infrastructure and renewable energy assignments., • Experience managing the design and construction of civil engineering, land development and infrastructure projects a plus., • 5+ years of Project Management experience., • 5+ years experience managing and/or implementing Section 94-C/Article 10, Section 102 and/or Article VII assignments., • Bachelor's degree in Civil Engineering, Master's degree a plus., • Possess valid New York State Professional Engineer licensure (can be another state if reciprocity pursued)., • Ability to effectively work independently and lead a team of multi-discipline technical professionals, and to mentor staff engineers., • Strong client development and client management abilities., • Experience in report and proposal writing., • Proficiency of AutoCAD or Civil 3D (preferred) with the ability to design site layouts from concept through completion., • Active participation in professional organizations., • Excellent written and verbal communication skills., • Strong attention to detail with excellent analytical, multitasking, and judgment capabilities., • Possess reliable transportation for client meetings and job site visits and a valid driver's license in good standing. Langan provides a rich array of programs and benefits to help its employees advance their careers and enhance the quality of their lives. Our comprehensive compensation package includes: full-time employment company paid medical, dental, and vision coverage; life insurance, short- and long-term disability insurance, and paid pregnancy disability leave; 401(k)/Roth with company match; paid time off including parental and military leave; employee referral and professional license bonuses; and educational reimbursement. Langan offers employee resource groups; flexible work schedules; extensive training; wellness programs; buddy and mentoring programs; and much more! Langan is committed to providing equal employment opportunities to all qualified applicants and employees, including individuals with disabilities and protected veterans. We believe that an inclusive workplace is essential for the well-being and success of our employees.

Construction Manager Job Responsibilities: Oversees construction sites, general contractors, and workers to ensure a high level of quality and safety. Assists in managing and reviewing the progress of contractors' construction schedules.

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Project Management Department: Project Management Reports to: Project Executive Supervisory Duties: Yes Salary Range: $181,000- $238,000 The Senior Project Manager (SPM) will be assigned to large complex projects or multiple projects and will serve as the main point of contact and corporate representative for all project stakeholders including Owners, OPM’s, developers, architects, engineers and subcontractors. The SPM is responsible for oversight of the entire project’s life cycle including budget, cost, schedule, risk, resource management and safety while providing exceptional customer service. The SPM will oversee the implementation of a Raving Fans action plan and will play a key role in business development including networking events, marketing initiatives, proposal preparation and interviews. Responsibilities / Essential Functions • Lead and communicate with Field Supervision, Subcontractors, and Vendors to assist them in working to the Project Schedule., • Represent Consigli with Owners, Architects, Consultants, Vendors and Subcontractors, • Administer all financial aspects of the project including management of Owner’s contract term and subcontracts agreements., • Build effective working relationships with clients and the project team members., • Manage multiple projects depending on size, complexity, and type., • Continuously coordinate with field staff (General Superintendent, Project Superintendent, Assistant Superintendent, Safety Manager, etc.) on project goals, budget and schedule., • Mentor staff: manage multiple team members on a single large project or multiple projects., • Provide formal evaluation(s) of team members on performance and progress., • Oversee training and professional development plans of team members and assist in implementation., • Take ownership in the development of relationships with new clients, Owners, Architect and Engineers to generate new opportunities., • Take lead in the development and management of optimal project profit opportunities including self-perform trades., • Participate in corporate and Project Management Department operations initiatives. Preconstruction Responsibilities, • Work with and support estimating throughout the proposal and preconstruction process., • Provide constructability reviews of drawings and budget updates as necessary., • Review prime contract and provide comments accordingly to ensure any specific contractual conditions are included in subcontract bidding documents., • Develop contract schedule with Superintendent., • Work closely with the Purchasing Department throughout the project procurement/buy-out process., • Take lead with identifying, managing and reporting project risks throughout life cycle., • Identify and take lead in the development of conversion action plans to push the projects from preconstruction into construction., • Develop project financial plan with Project Executive and oversee initial budget development and project set-up. Project Management, • Attend and run weekly owner/architect/contractor (OAC) project meetings and subcontractor meetings; and manage the preparation and distribution of meeting minutes., • Manage and support the maintenance of project logs (RFI’s, submittals, change requests, etc.)., • Coordinate with Project Scheduler to update and distribute project master schedule with input from Superintendent and project teams., • Manage and support cost reporting, forecasting, budget and change management throughout the lifecycle of the project., • Oversee all project reporting activities including Owner meetings, internal cost meetings, financial meetings and monthly reports., • Assist the project Superintendent and other team members in the resolution of all critical issues, RFI’s, etc. with a focus on quality, cost and schedule., • Manage timely reviews and approval of invoices and subcontractor requisitions., • Manage the requisition process: maintain and report cash flow throughout the project and address/communicate issues proactively and promptly. Key Skills • A driven leader who spearheads Consigli’s corporate culture of Raving Fans., • Excellent business judgment demonstrated by consistently achieving project objectives while developing/maintaining outstanding relationships with Owner, Architect and Subcontractors., • Develop and utilize business development skills in addition to project management responsibilities., • Excellent organizational skills and attention to detail evidenced by a strong command of all applicable contract and legal provisions., • Ability to multi-task and handle competing priorities., • A strong sense of urgency and self-initiative., • Strong problem-solving skills and the ability to confidently and decisively take action., • Team leader with excellent diplomatic and communication skills, able to handle and resolve conflicts effectively in a firm but fair manner., • Train, develop and mentor team members., • Full understanding of corporate profit models and institute opportunities to optimize margins. Required Experience • A bachelor's degree in engineering, Construction Management or Architecture preferred., • A minimum of 10-15 years of experience within the construction industry in Project Management or similar role., • OSH 10 and OSHA-30 preferred., • Additional proficiencies shall include cost management software (Timberline, Sage preferred), scheduling software (Primavera P6 preferred) and construction management software (Procore preferred)., • Knowledge and understanding of all PM, APM and PE, Superintendent and Assistant Superintendent responsibilities.

Job Description WESTCHESTER, NY Job Title: • Project Manager I Who we are: Callahan Construction Managers is a full-service construction management company based in Bridgewater MA, with regional offices in White Plains, NY. Callahan has served the New England and Northeast regions as a family business for over 70 years. As one of the region’s largest open shop construction firms, Callahan provides a wide range of preconstruction and construction management services to local, regional, and national clients. Callahan enforces a high quality and innovative approach to all projects, including multi-family residential, senior housing, affordable housing, hospitality, life sciences, corporate office, educational, retail and other markets. Visit www.callahan-inc.com for more information. Summary/Objective: The Project Manager (PM I) will serve as a vital team member partnering with the Lead Superintendent while reporting to the Project Executive on the full scope of the project. The PM I will be responsible for Document Control & Procurement Management, Communication, Cost Management, Project Reporting Management & People Management while representing Callahan Construction Managers throughout the full project cycle. The PM I will also have complete oversight in managing the Assistant Project Manager on task completion. Essential functions: Safety • Assist the Lead Superintendent in developing and maintaining a safety culture for the project., • Perform 4 safety inspections per month, • Discuss safety at weekly team meetings Document Control and Procurement Management • Understand the Plans, Specifications & Contracts of the project, • Understand the Owner Contract, including terms, qualifications, allowances, phasing, and logistics, • Track and manage all critical material deliveries throughout the project duration (submittal management and procurement log), • Manage risk prevention on site (Subcontractors and 3rd tier Subcontractors) by ensuring subcontracts, insurances, and Exhibit Q-1s are in place prior to mobilization Communication: • Develop & maintain positive, professional relationships with the Owner, Architect, Subcontractors and Project Team, • Manage the daily activities of the project and proactively plan for upcoming needs, • Control the prompt flow of information to Owners, Consultants & Subcontractors, • Effective presentation skills for project updates, • Effective communication with subcontractor PM and Foremen to establish good working relationship, minimize conflicts and encourage bidding on other Callahan projects. Cost Management: • Project Buyout o Create detailed & complete scopes of work o Scope review of all bidders and negotiation of the best price and scope for Callahan o Complete Buyout in advance of the needs of the project schedule • Review and supervision of the job cost control system o Set up job cost budgets o Monitor and manage all field purchases o Monitor and manage labor usage o Responsible for the bottom-line project profitability • Creating and updating of monthly cost report, including accurate forecasting of cost to complete projection, • Coordinating & Leading quarterly cost meetings, • Oversee the monthly Owner & Subcontractor Requisition processes o Monitoring & Reviewing 3rd tier vendor payment compliance • Leading and executing change management processes, • Reviewing change requests against subcontract scopes of work, • Working along with the APM, promptly pricing all change requests, thoroughly vetting all Subcontractors pricing, and submitting accurate proposals to the Owner with time extensions where required, • Overseeing prompt issuance of Subcontractor change orders to keep work flowing on site, • Effectively negotiate subcontractor change orders that impact the “bottom line” Project Management & Reporting: • Creating the baseline schedule & taking an active part in monthly schedule updates that accurately reflect current procurement status, shop drawing process, project impacts and delays, and Subcontractor staffing and production. Assist with the development of break out schedules for critical or complex areas, • Planning work in advance to eliminate conflicts in plans, specifications or between trades, • Review and supervise Risk Management & Safety Program to protect Callahan against personal injury, property damage and public liability, • Plan and manage the turnover process with field staff, • Prepare and take appropriate actions in relation to union interruptions People Management: • Managing & ensuring accuracy of APM work product, • Leading team to ensure project success, • Mentoring Assistant Project Managers Required education and experience: • Bachelor’s Degree (Preferably Engineering, Construction Management or Architecture), • 5+ Years Experience, • Prior Experience in a construction setting (Construction Management) All qualified applicants will be afforded equal opportunity. There shall be no discrimination based on race, color religion, sex, sexual orientation, gender identity, national original or on an applicant’s status as a protected veteran or as individual with a disability.

Job Description Employment Type: Full-Time FSLA: Salary/Exempt Division: Field Operations Department: Field Operations Reports to: General Superintendent Supervisory Duties: Yes Salary Range: $167,000 - $225,000 Reporting to the General Superintendent, the Senior Superintendent provides overall administrative and technical management of the construction project. The Senior Superintendent manages all on site construction activities including self-perform labor, subcontractors and consultants to successfully execute large and complex projects. Responsibilities / Essential Functions • Administer project safety program to maintain a safe and healthy work environment., • Proficient in all five areas of focus on their project:, • Safety, Schedule, Cost, Quality, and creating Raving Fans with all external partners., • Develop and implement a site-specific safety plan for each project assigned., • Verify that all subcontractors have a valid subcontract and an acceptable insurance certificate prior to working on site., • Serve as the OSHA competent person for various tasks or assign others to serve as competent person., • Preplan all operations to produce innovative and efficient methods to avoid hazards. Senior Superintendent must correct all recognized hazards immediately., • Supervise construction effort to ensure project is constructed in accordance with the plans and specifications., • Thoroughly understand the contract (owner/subcontractor), owner requirements, contract plans, contract specifications, submittals and any change documents, • Provide technical assistance on the project, interpret contract drawings and submittals, and develop construction methods consistent with contract documents., • Work with the project team to set project goals and schedule milestones., • Coordinate all required labor, equipment, small tools, permanent materials, and supplies as needed for self-perform operations., • Create the Site-Specific Quality Plan (SSQP), manage all aspects of project quality efforts., • Complete onsite material verification as required for the project., • Manage project budget requirements:, • Assist the Project Manager in developing budgets and monthly costs to complete., • Manage T&M process, including verification of time and materials., • Track production and submit quantities weekly., • Identify changes in the field, authorize field change requests, provide all documentation required to ensure compensation for all work performed., • Assist in the approval process for all subcontractor requisitions., • Manage the project to meet schedule requirements and milestones., • Develop a baseline schedule with Project Services Group., • Track progress against baseline schedule and critical path dates., • Communicate schedule requirements at weekly subcontractor meetings., • Develop a short-term plan on a weekly basis that directly supports the project schedule and looks ahead a minimum of 3 weeks., • Coordinate and lead the daily stand up and weekly foreman meetings., • Ensure that the material delivery log is updated and accurate., • Interface with client representatives, A-E representatives, other contractors, and various building officials in a professional manner., • Participate in business development. Create Raving Fans on current projects. Utilize contacts to initiate leads for future projects., • Participate in quarterly Superintendent and Safety meetings, as well as periodic training sessions., • Supervise assigned Foremen, Assistant Superintendents, and Project Engineers. Key Skills • Self-starter with ability to set goals and tasks with strong leadership skills., • Strong communication skills. Required Experience • Bachelor’s degree required, preferred in Construction Management/Civil Engineering., • 3-7 years of experience in the construction or related field in a similar role or 7-10 years in a supervisory role as a tradesperson., • Understands building plans and specifications., • Safety standards knowledge and enforcement, OSHA 30 required.

Job Description Gunner Roofing is soaring ahead as the fastest-growing roofing company, known for exceptional craftsmanship, stellar customer service, and innovative technology. We’ve patented a unique website that makes us the first and only company in the nation to provide accurate roof quotes completely online, in just minutes. Winner of multiple awards including GAF’s Cutting Edge Contractor Award 2023 & DaVinci Masterpiece Contractor Project of the Year 2023 along with Fast Company’s Most Innovative Companies 2024, & Inc. Best Workplaces 2025. Our people are the backbone of Gunner, each member bringing unique skills and passion to the table, driving us forward and upholding our commitment to education, communication, unmatched speed, innovation, and craftsmanship. Our people are aided by an experience that enables customers to easily purchase roofing online. This blend of traditional craftsmanship and digital ease underscores our dedication to an exceptional customer experience. What part will you play? • As a Roofing Project Manager at Gunner, you’ll be the driving force behind every remodeling project once it’s sold. You’ll oversee all aspects of execution, ensuring contracts are delivered flawlessly, on time, and to the highest standard. Acting as the on-site leader, you’ll manage subcontractors, safeguard quality, ensure safety compliance, and deliver a remarkable customer experience from start to finish — with minimal supervision and maximum impact. You own the homeowner relationship from the first walkthrough to the final handshake. You are the person they call, and the reason they refer us to a neighbor. What will you do? • Serve as the on-site expert, leader, and primary communicator for assigned projects., • Coordinate with dispatch, procurement, and customer success teams to keep projects running smoothly., • Supervise and lead subcontractors and crews — ensuring safety, teamwork, discipline, and high-quality workmanship., • Review and understand the project scope and specifications before work begins., • Track and verify material and equipment deliveries, reporting discrepancies to procurement., • Advise customers on potential scope changes and process change orders directly., • Ensure OSHA compliance and adherence to all applicable regulations., • Monitor and inspect installation quality throughout each project., • Communicate proactively and effectively with both customers and internal teams at every stage., • Own escalations personally. When something goes wrong on a job, you are the one who calls the homeowner first, explains it plainly, and makes it right., • Use technical knowledge, attention to detail, and customer service skills to start, run, and close projects on time., • Perform other duties as assigned. Compensation • Base Salary: $90,000 - $120,000, • Two-week onboarding program, • American Express for business expenses, • Company Gas Card, • Company Vehicle, including insurance and fuel coverage Requirements • 2+ years in construction project management or site supervision with direct customer interaction., • Hands-on experience in residential construction; experience with roofing, siding, and/or window and door installation is ideal., • Proven ability to deliver 5-star experiences to clients., • A track record of being the person a homeowner calls: de-escalating problems, recovering a job that went sideways, and turning a frustrated customer into a referral., • Strong skills in guiding teams, enforcing standards, and managing performance., • Excellent written, verbal, and interpersonal skills., • Familiarity with Google Workspace and DocuSign., • Ability to manage schedules using a digital calendar., • Understanding of contracts, subcontracts, and terms & conditions., • Self-motivated, disciplined, resourceful, and comfortable working with ambiguity., • Professional demeanor and presentation., • OSHA certifications., • Valid driver’s license with an acceptable driving record, and demonstrated adherence to company safety standards., • Willingness to learn and grow with the company., • Ready to walk us through one specific job that went wrong and exactly what you said to the homeowner. We will ask, and it is the part of the interview that matters most. Benefits • 401(k): Company match after 6 months, • United Healthcare (medical, dental, vision) with company contribution after 60 days, • PTO: Unlimited plan after 60 days

Job Description Job Title: Construction Project Manager – Ground-Up & Interior Renovation Projects Location: Westchester County & NYC (5 Boroughs) Compensation: $125,000 – $170,000+ based on experience Schedule: Full-Time | In-Office / On-Site | No Remote or Hybrid About the Opportunity Our client, a highly respected and growing construction management/general contracting firm, is seeking experienced Construction Project Managers to oversee a diverse portfolio of commercial construction projects throughout Westchester County and the NYC 5 Boroughs. This role is ideal for professionals with strong experience managing ground-up construction and/or interior renovation projects across sectors such as commercial office, retail, mixed-use, hospitality, and corporate interiors. The company offers long-term growth, a collaborative team environment, and a steady pipeline of active projects throughout the region. Key Responsibilities • Manage projects from pre-construction through closeout, • Oversee all aspects of scheduling, budgeting, subcontractor coordination, procurement, and project execution, • Lead day-to-day communication with clients, architects, engineers, consultants, and field teams, • Review and manage RFIs, submittals, change orders, contracts, and project documentation, • Coordinate with Superintendents to ensure project schedules, safety standards, and quality expectations are maintained, • Track project costs and maintain budget control throughout all phases, • Conduct regular project meetings and provide detailed progress updates to stakeholders, • Ensure all work complies with local building codes, safety regulations, and company standards, • Identify and proactively resolve project challenges to minimize delays and cost impacts, • Maintain strong relationships with clients, vendors, and subcontractors throughout the project lifecycle Qualifications • Minimum 5–10+ years of Project Management experience within the construction industry, • Proven experience managing:, • Ground-up construction projects, • Interior renovation / fit-out projects, • Commercial, retail, mixed-use, hospitality, or corporate interiors projects, • Strong knowledge of NYC and Westchester construction processes and regulations, • Procore proficiency is required, • Experience with project scheduling, budgeting, buyouts, and subcontractor management, • Ability to manage multiple projects simultaneously in a fast-paced environment, • Excellent leadership, communication, and organizational skills, • Strong understanding of construction drawings, specifications, and project sequencing, • Bachelor’s degree in Construction Management, Engineering, Architecture, or related field preferred Additional Information • Stable pipeline of active projects throughout NYC and Westchester, • Highly visible role with opportunity for long-term advancement, • Competitive compensation package based on experience, • Full-time in-office and field presence required If you are an experienced Construction Project Manager seeking a long-term opportunity with a well-established and growing construction firm, we encourage you to apply.

Job Description Title: Mechanical Project Manager Job Description Under the general direction of the Project Executive, the Project Manager provides effective leadership ensuring the construction schedules, safety, quality standards, customer satisfaction, trade partners' effectiveness, and maximum profitability are maintained throughout the project’s progress. The Project Manager is accountable for the overall performance of the assigned project(s) and is responsible for understanding, planning, executing, controlling, monitoring, reviewing, and delivering the project with the support of the project team. Additionally, The Project Manager assigned under Mechanical Construction Department is responsible for direct field supervision of their labor force performing the work. Organizational Planning and Scheduling Review contract documents, clarify the scope and resolve discrepancies Prepare project’s budget and schedule of values Identify permits, licenses, and procedures required in place prior to commencement of work Create and enforce project-specific quality and safety standards Review and complete buyouts, identify contract scope omissions and amend subcontracts as necessary Generate a comprehensive project schedule, with the assistance of project team and trades involved, incorporating client’s milestones and required phasing. Establish a streamlined process for pre-construction, construction, and project close-out phase Procure major equipment Project Monitoring Track progress to ensure completion of work within target deadlines Conduct monthly production control and cashflow projections meetings Identify and resolve issues impacting budget and/or schedule Screen RFIs, submittals, and other project deliverables for contract compliance Review change order submissions Review monthly payment requisitions and subcontractor payments Review documents submitted in Electronic Document Management Software (EDMS) for completeness Communication Enforce fulfillment of responsibilities following ICSC internal procedures Assign tasks to project team and subcontractors based on priority, importance, and schedule Attend meetings with the owner, client, subcontractors, and staff Coordinate in house manpower and resources with other project managers Establish and maintain relationships internally and externally of ICSC Leadership Competency Lead and motivate project personnel Deliver ongoing feedback and address performance issues Perform staff performance evaluations Recognize training needs and ensure that staff gain needed skills Suggest appropriate training opportunities and assignments Engage staff in using best-practice tools and methodology Administrative Duties Issue notices to clients, vendors, and subcontractors related to contract changes Use designated timekeeping software for personal timekeeping Record minutes from the attended meetings Coordinate and approve vacation time with the staff members Review and approve staff’s expense reports Supervisory Commitment Direct construction activities of the subcontractors, laborers, and other staff as assigned Adhere and support the organization’s safety, observing OSHA and all state-level agency regulations (MTA, SCA, etc..) Inspect materials for conformance against approved documents and specifications Monitor work to ensure adherence to plans and specifications, and construction schedule Identify, procure and manage resources required to finish company self-performed activities Schedule and facilitate inspections Assist with startup and commissioning Complete daily reports Qualifications and Skills 5 years of mechanical construction related experience Strong oral and written communication. Excellent time management skills.

New York Power Authority seeks an experienced Project Manager to lead highly complex projects from initiation through closeout. The role requires an engineering background (Civil/Mechanical/Electrical), 6+ years in project/construction management, and familiarity with codes, permits, safety, and ven